{ "id": 5138677, "name": "ARTHUR B. MENDELSON, Plaintiff-Appellant and Cross-Appellee, v. BEN A. BORENSTEIN AND COMPANY, Defendant-Appellee and Cross-Appellant", "name_abbreviation": "Mendelson v. Borenstein", "decision_date": "1992-12-14", "docket_number": "No. 1-91-0645", "first_page": "605", "last_page": "621", "citations": [ { "type": "official", "cite": "240 Ill. App. 3d 605" } ], "court": { "name_abbreviation": "Ill. App. Ct.", "id": 8837, "name": "Illinois Appellate Court" }, "jurisdiction": { "id": 29, "name_long": "Illinois", "name": "Ill." }, "cites_to": [ { "cite": "589 N.E.2d 933", "category": "reporters:state_regional", "reporter": "N.E.2d", "weight": 2, "opinion_index": 0 }, { "cite": "226 Ill. App. 3d 526", "category": "reporters:state", "reporter": "Ill. App. 3d", "case_ids": [ 5239322 ], "weight": 2, "opinion_index": 0, "case_paths": [ "/ill-app-3d/226/0526-01" ] }, { "cite": "596 N.E.2d 731", "category": "reporters:state_regional", "reporter": "N.E.2d", "weight": 2, "year": 1992, "opinion_index": 0 }, { "cite": "231 Ill. App. 3d 639", "category": "reporters:state", "reporter": "Ill. App. 3d", "case_ids": [ 5202273 ], "weight": 2, "year": 1992, "opinion_index": 0, "case_paths": [ "/ill-app-3d/231/0639-01" ] }, { "cite": "550 N.E.2d 665", "category": "reporters:state_regional", "reporter": "N.E.2d", "opinion_index": 0 }, { "cite": "193 Ill. App. 3d 963", "category": "reporters:state", "reporter": "Ill. App. 3d", "case_ids": [ 2496817 ], "opinion_index": 0, "case_paths": [ "/ill-app-3d/193/0963-01" ] }, { "cite": "574 N.E.2d 230", "category": "reporters:state_regional", "reporter": "N.E.2d", "year": 1990, "opinion_index": 0 }, { "cite": "214 Ill. App. 3d 427", "category": "reporters:state", "reporter": "Ill. App. 3d", "case_ids": [ 5298365 ], "year": 1990, "opinion_index": 0, "case_paths": [ "/ill-app-3d/214/0427-01" ] }, { "cite": "595 N.E.2d 1223", "category": "reporters:state_regional", "reporter": "N.E.2d", "weight": 2, "year": 1991, "opinion_index": 0 }, { "cite": "230 Ill. App. 3d 959", "category": "reporters:state", "reporter": "Ill. App. 3d", "case_ids": [ 5211269 ], "weight": 2, "year": 1991, "opinion_index": 0, "case_paths": [ "/ill-app-3d/230/0959-01" ] }, { "cite": "592 N.E.2d 190", "category": "reporters:state_regional", "reporter": "N.E.2d", "opinion_index": 0 }, { "cite": "227 Ill. App. 3d 623", "category": "reporters:state", "reporter": "Ill. App. 3d", "case_ids": [ 5795258 ], "opinion_index": 0, "case_paths": [ "/ill-app-3d/227/0623-01" ] }, { "cite": "437 N.E.2d 774", "category": "reporters:state_regional", "reporter": "N.E.2d", "opinion_index": 0 }, { "cite": "107 Ill. App. 3d 373", "category": "reporters:state", "reporter": "Ill. App. 3d", "case_ids": [ 3023870 ], "opinion_index": 0, "case_paths": [ "/ill-app-3d/107/0373-01" ] }, { "cite": "586 N.E.2d 1211", "category": "reporters:state_regional", "reporter": "N.E.2d", "weight": 5, "year": 1982, "pin_cites": [ { "page": "1215-16" } ], "opinion_index": 0 }, { "cite": "146 Ill. 2d 263", "category": "reporters:state", "reporter": "Ill. 2d", "case_ids": [ 5597010 ], "weight": 5, "year": 1982, "pin_cites": [ { "page": "273" } ], "opinion_index": 0, "case_paths": [ "/ill-2d/146/0263-01" ] }, { "cite": "110 Ill. App. 210", "category": "reporters:state", "reporter": "Ill. App.", "case_ids": [ 2557540 ], "opinion_index": 0, "case_paths": [ "/ill-app/110/0210-01" ] }, { "cite": "365 N.E.2d 360", "category": "reporters:state_regional", "reporter": "N.E.2d", "year": 1903, "opinion_index": 0 }, { "cite": "48 Ill. App. 3d 73", "category": "reporters:state", "reporter": "Ill. App. 3d", "case_ids": [ 3374754 ], "year": 1903, "opinion_index": 0, "case_paths": [ "/ill-app-3d/48/0073-01" ] }, { "cite": "381 N.E.2d 1023", "category": "reporters:state_regional", "reporter": "N.E.2d", "year": 1977, "opinion_index": 0 }, { "cite": "64 Ill. App. 3d 867", "category": "reporters:state", "reporter": "Ill. App. 3d", "case_ids": [ 3330398 ], "year": 1977, "opinion_index": 0, "case_paths": [ "/ill-app-3d/64/0867-01" ] }, { "cite": "519 N.E.2d 991", "category": "reporters:state_regional", "reporter": "N.E.2d", "pin_cites": [ { "page": "994" } ], "opinion_index": 0 }, { "cite": "166 Ill. App. 3d 339", "category": "reporters:state", "reporter": "Ill. App. 3d", "case_ids": [ 5070411 ], "pin_cites": [ { "page": "343" } ], "opinion_index": 0, "case_paths": [ "/ill-app-3d/166/0339-01" ] }, { "cite": "58 N.E. 355", "category": "reporters:state_regional", "reporter": "N.E.", "year": 1988, "opinion_index": 0 }, { "cite": "187 Ill. 316", "category": "reporters:state", "reporter": "Ill.", "case_ids": [ 3230471 ], "year": 1988, "opinion_index": 0, "case_paths": [ "/ill/187/0316-01" ] }, { "cite": "565 N.E.2d 93", "category": "reporters:state_regional", "reporter": "N.E.2d", "opinion_index": 0 }, { "cite": "206 Ill. App. 3d 881", "category": "reporters:state", "reporter": "Ill. App. 3d", "case_ids": [ 2558557 ], "opinion_index": 0, "case_paths": [ "/ill-app-3d/206/0881-01" ] }, { "cite": "567 N.E.2d 1083", "category": "reporters:state_regional", "reporter": "N.E.2d", "year": 1990, "opinion_index": 0 }, { "cite": "209 Ill. App. 3d 655", "category": "reporters:state", "reporter": "Ill. App. 3d", "case_ids": [ 2543284 ], "year": 1990, "opinion_index": 0, "case_paths": [ "/ill-app-3d/209/0655-01" ] }, { "cite": "570 N.E.2d 1152", "category": "reporters:state_regional", "reporter": "N.E.2d", "year": 1991, "opinion_index": 0 }, { "cite": "212 Ill. App. 3d 318", "category": "reporters:state", "reporter": "Ill. App. 3d", "case_ids": [ 2599513 ], "year": 1991, "opinion_index": 0, "case_paths": [ "/ill-app-3d/212/0318-01" ] }, { "cite": "585 N.E.2d 1164", "category": "reporters:state_regional", "reporter": "N.E.2d", "year": 1989, "opinion_index": 0 }, { "cite": "223 Ill. App. 3d 819", "category": "reporters:state", "reporter": "Ill. App. 3d", "case_ids": [ 5256165 ], "year": 1989, "opinion_index": 0, "case_paths": [ "/ill-app-3d/223/0819-01" ] }, { "cite": "489 N.E.2d 867", "category": "reporters:state_regional", "reporter": "N.E.2d", "weight": 2, "pin_cites": [ { "page": "871" }, { "page": "871" } ], "opinion_index": 0 }, { "cite": "111 Ill. 2d 229", "category": "reporters:state", "reporter": "Ill. 2d", "case_ids": [ 3166688 ], "weight": 2, "pin_cites": [ { "page": "240" }, { "page": "240" } ], "opinion_index": 0, "case_paths": [ "/ill-2d/111/0229-01" ] }, { "cite": "83 Ill. 2d 344", "category": "reporters:state", "reporter": "Ill. 2d", "case_ids": [ 5473189 ], "pin_cites": [ { "page": "349-50" } ], "opinion_index": 0, "case_paths": [ "/ill-2d/83/0344-01" ] }, { "cite": "49 Ill. 2d 131", "category": "reporters:state", "reporter": "Ill. 2d", "case_ids": [ 2909764 ], "weight": 2, "pin_cites": [ { "page": "135-36" }, { "page": "135-36" } ], "opinion_index": 0, "case_paths": [ "/ill-2d/49/0131-01" ] }, { "cite": "579 N.E.2d 824", "category": "reporters:state_regional", "reporter": "N.E.2d", "weight": 6, "pin_cites": [ { "page": "826" }, { "page": "826" }, { "page": "828" } ], "opinion_index": 0 }, { "cite": "144 Ill. 2d 232", "category": "reporters:state", "reporter": "Ill. 2d", "case_ids": [ 5592343 ], "weight": 6, "pin_cites": [ { "page": "236" }, { "page": "236-37" }, { "page": "240" } ], "opinion_index": 0, "case_paths": [ "/ill-2d/144/0232-01" ] }, { "cite": "549 N.E.2d 1262", "category": "reporters:state_regional", "reporter": "N.E.2d", "weight": 6, "year": 1991, "pin_cites": [ { "page": "1263" }, { "page": "1263-64" }, { "page": "1264" }, { "page": "1264-65" } ], "opinion_index": 0 }, { "cite": "133 Ill. 2d 342", "category": "reporters:state", "reporter": "Ill. 2d", "case_ids": [ 3260057 ], "weight": 7, "year": 1991, "pin_cites": [ { "page": "344" }, { "page": "344" }, { "page": "344" }, { "page": "347" }, { "page": "347" } ], "opinion_index": 0, "case_paths": [ "/ill-2d/133/0342-01" ] } ], "analysis": { "cardinality": 1335, "char_count": 37748, "ocr_confidence": 0.776, "pagerank": { "raw": 2.138166047858225e-07, "percentile": 0.7667806115337226 }, "sha256": "346afc2927c9826edf6059d8d93a0c0f58721da4586a1f88c9be647de5df90e7", "simhash": "1:f43057e76f501d18", "word_count": 5922 }, "last_updated": "2023-07-14T17:58:37.771033+00:00", "provenance": { "date_added": "2019-08-29", "source": "Harvard", "batch": "2018" }, "casebody": { "judges": [], "parties": [ "ARTHUR B. MENDELSON, Plaintiff-Appellant and Cross-Appellee, v. BEN A. BORENSTEIN AND COMPANY, Defendant-Appellee and Cross-Appellant." ], "opinions": [ { "text": "PRESIDING JUSTICE BUCKLEY\ndelivered the opinion of the court:\nPlaintiff Arthur B. Mendelson filed this suit to recover damages against defendant Ben A. Borenstein & Company based on defendant\u2019s alleged breach of the parties\u2019 construction contract. The circuit court of Cook County entered summary judgment against plaintiff and simultaneously denied plaintiff leave of court to file a third-amended complaint. Plaintiff filed a motion for reconsideration which the circuit court denied. Defendant thereafter filed a petition for sanctions against plaintiff pursuant to Supreme Court Rule 137 (134 Ill. 2d R. 137). Defendant\u2019s petition was denied. Plaintiff appeals from the award of summary judgment and the court\u2019s refusal to permit plaintiff to file a third-amended complaint. Defendant cross-appeals from the denial of his petition for sanctions. We affirm.\nOn March 20, 1989, plaintiff filed his initial breach of contract action against defendant relating to defendant\u2019s construction of a strip shopping center at the corner of Madison Street and Central Avenue in Chicago. After the grant of various motions to dismiss, plaintiff filed a second-amended complaint on November 3,1989.\nPlaintiff\u2019s second-amended complaint alleges that in 1982, the property in question was improved with a building which was destroyed by fire. After the fire, the debris from the destroyed building was dropped into the previous structure\u2019s basement. It is undisputed that both parties knew of the rubbled condition of the property.\nOn September 17, 1984, plaintiff entered an oral contract with defendant for the construction of a strip shopping center on the property. The parties thereafter drafted a written contract confirming the material terms of their oral agreement. The parties never signed the contract but have, according to plaintiff, governed themselves in accordance with its specifications and requirements.\nSection 12.1.1 of the agreement defined a \u201cChange Order\u201d as \u201ca written order to the Contractor signed by the Owner and the Architect, issued after execution of the Contract, authorizing a change in the Work or an adjustment in the Contract Sum or Contract Time.\u201d \u201cWork\u201d to be performed by the contractor was defined as \u201cthe completed construction required by the Contract Documents,\u201d which in turn consisted of, among other matters, the architect\u2019s plans and specifications.\nThe specific paragraphs of plaintiff\u2019s second-amended complaint relevant to this appeal are the following:\n\u201c6. At all times relevant ***, it was a material express term of the parties\u2019 contract, that [defendant] would use its best skill and judgment in following the plans and specifications drawn for the project, and would cooperate with the architect in furthering the interests of [plaintiff] throughout the course of completion of the project.\n7. Notwithstanding [defendant\u2019s] express duties described above, [defendant] did materially breach such duties in unilaterally deviating from [the] Project\u2019s] plans and specifications, as they pertained to footing and foundation excavation, without the approval of the architect as required under Paragraph *** of the General Conditions of the Contract.\n8. More specifically, upon discovering the nature and extent of the poor soil conditions at the Project, [defendant] unilaterally abandoned the Project plans and specifications which *** originally specified that footings would be set at a depth of one foot, eight inches *** and instead, excavated a trench, refilled it with recycled concrete and set the Project footings upon such refilled trench.\u201d\nDiscovery between the parties included the deposition of Sherwin Braun, the project\u2019s architect, the affidavit of Alvin Frishman, defendant\u2019s project manager, and documents identified by Braun and Frishman. These materials formed the basis of defendant\u2019s summary judgment motion.\nBraun testified that he and defendant were familiar with one another from other projects and that defendant introduced his firm to plaintiff. Braun learned that plaintiff and defendant were also very familiar with one another.\nBraun testified that his firm entered a contract with plaintiff fdr Braun\u2019s firm to perform architectural services. These services included developing specifications for the building, for which Braun hired a structural engineering firm, creating contract documents for construction, and observing the construction process, during which Braun was to advise and consult with plaintiff and served as his representative. Plaintiff never complained about the specifications as originally drawn.\nAll parties knew of the rubbled condition of the property. Prior to construction, the parties contemplated that the footings may have to be changed because the extent of the rubble was unknown. The construction plans were drawn with the footings at a standard four feet below \u201czero zero.\u201d During the construction process, it became clear to all parties that the footings could not be placed as specified in the initial plans. A meeting was accordingly held at defendant\u2019s offices. Plaintiff, Braun, defendant and a soil engineer attended the meeting. The parties discussed various options, including removing the rubble, compacting all the rubble, lowering the footings to virgin soil, and installing compacted fill where the footings were to be placed. All of these options, however, were determined to be prohibitively expensive.\nThe soil engineer recommended excavating a five-foot trench down to virgin soil, filling it with recycled concrete, and placing the footings on the concrete. Braun contacted his structural engineer, who approved the solution. Braun considered this option to be the appropriate solution and would have recommended another course of action if he thought otherwise. Defendant proceeded with the placement of the footings in accordance with the meeting.\nFrishman\u2019s affidavit corroborates Braun\u2019s testimony in all material respects. All parties knew that the rubbled condition would have to be treated during the construction process. At the meeting held to address the problem, options were discussed, and one was selected: A five-foot-wide trench would be dug to virgin soil, with the trench being filled with recycled concrete. The footings would be placed on the concrete. Plaintiff, Braun and the structural engineer specifically approved this method.\nOn October 11, 1984, Frishman sent a letter to plaintiff confirming this agreement, and he sent a copy of the letter to the architect. Defendant then carried out the agreed solution. Plaintiff and his architect observed the work in progress. The architect issued a \u201cCertificate of Substantial Completion\u201d on January 16, 1986.\nIn response to defendant\u2019s motion, plaintiff submitted his own affidavit wherein he states that he was familiar with defendant from prior dealings and introduced to the architect by defendant. During the construction process, plaintiff learned from defendant that the foundations could not be set as originally specified in the written contract. Based on defendant\u2019s advice that a soil engineer would assist in deciding the best method of setting the foundations, plaintiff authorized defendant to obtain the services of a soil engineer.\nIn October 1984, a meeting was held between plaintiff, defendant and the soil engineer; the architect may not have been present. At the meeting, plaintiff was advised that the most cost effective way of dealing with the problem would be to excavate a trench and fill it with concrete. Plaintiff relied on this advice and had insufficient knowledge himself to know the propriety of the proposed solution. Plaintiff never sought the advice of his architect. As with the problem associated with the footings, plaintiff relied principally on defendant and not his architect when other problems arose.\nAt the October 24, 1990, hearing on defendant\u2019s summary judgment motion, defendant argued that plaintiff consented to any deviation from the contract\u2019s plans and specifications as well as the procedure for effecting such deviations. Thus, plaintiff\u2019s allegation that defendant \u201cunilaterally\u201d deviated or abandoned the specifications was without merit. Independently, defendant argued that res judicata barred plaintiff\u2019s action. On this matter, defendant argued that plaintiff\u2019s consent to a judgment in an action by defendant on a promissory note representing the unpaid contract price amounted to res judicata on the issue of defendant\u2019s performance.\nThe circuit court granted defendant\u2019s motion for summary judgment. The court found that no written contract existed and that plaintiff agreed to the manner in which defendant handled the rubbled condition. After the court orally indicated how it would rule, plaintiff orally moved for leave of court to file a third-amended complaint alleging defendant\u2019s failure to perform in a workmanlike manner. The court, although recognizing its discretion to allow the amendment, found no evidence to support plaintiff\u2019s position. Leave of court, therefore, was denied. Plaintiff never tendered an amended complaint to the court, and no such complaint is in the record.\nOn November 21, 1990, plaintiff filed a motion for reconsideration, which provided in its entirety:\n\u201cMOTION FOR RECONSIDERATION Now comes the plaintiff *** and moves this Honorable Court to reconsider its Order of October 24, 1990, granting the defendant\u2019s motion for summary judgment and further, moves this Honorable Court for leave to file a memorandum in support therefor, within fourteen (II) days of the hearing of the instant motion.\u2019\u2019 (Emphasis added.)\nOn November 28, 1990, defendant objected to the jurisdiction of the court to hear plaintiff\u2019s motion. Defendant asserted that the motion did not qualify as a \u201cpost-trial\u201d motion and, therefore, the court lost jurisdiction 30 days following the grant of summary judgment. On December 4, 1990, the court ordered that plaintiff be allowed to file a reply to defendant\u2019s objection. The matter was continued until January 11,1991.\nOn January 11, 1991, the circuit court overruled defendant\u2019s objection to jurisdiction, set a hearing on plaintiff\u2019s motion to reconsider and ordered that no further briefs be filed. The transcript of this hearing is not in the record.\nOn February 5, 1991, the court denied plaintiff\u2019s motion for reconsideration. Plaintiff filed his notice of appeal on February 19, 1991.\nOn February 28, 1991, defendant filed a petition for sanctions under Supreme Court Rule 137 (134 Ill. 2d R. 137). Defendant based his petition on plaintiff\u2019s failure to investigate his claim that defendant\u2019s deviation from the written contract was \u201cunilateral.\u201d Defendant contended that an investigation would have revealed to plaintiff that, contrary to his complaint, both he and his architect approved of defendant\u2019s deviation from the plans. The circuit court denied defendant\u2019s petition for fees on April 19, 1991. Defendant has pursued a cross-appeal from this denial.\nBefore addressing the merits of plaintiff\u2019s appeal, we must address defendant\u2019s argument that we lack appellate jurisdiction. In support of its argument, defendant contends that plaintiff\u2019s motion for reconsideration is, as a matter of law, fatally deficient under section 2 \u2014 1203 of the Code of Civil Procedure (Ill. Rev. Stat. 1987, ch. 110, par. 2 \u2014 1203). Defendant particularizes this deficiency by noting that the motion, while entitled \u201cMotion for Reconsideration\u201d and requesting such relief, fails to articulate any grounds to warrant the grant of such relief. Relying on Andersen v. Resource Economics Corp. (1990), 133 Ill. 2d 342, 549 N.E.2d 1262, and Beck v. Stepp (1991), 144 Ill. 2d 232, 579 N.E.2d 824, defendant argues that this defect denies \u201cpost-judgment\u201d motion status to plaintiff\u2019s motion. Defendant accordingly contends that, as the motion did not extend the 30-day time limit in which to file a notice of appeal from a final judgment of the circuit court (see 134 Ill. 2d R. 303(a)), plaintiff\u2019s present appeal is untimely. We disagree.\nSection 2 \u2014 1203 of the Code of Civil Procedure governs post-judgment motions in nonjury cases:\n\u201c\u00a72 \u2014 1203. Motions after judgment in non-jury cases (a) In all cases tried without a jury, any party may, within 30 days after the entry of the judgment ***, file a motion for a rehearing, or a retrial, or modification of the judgment, or to vacate the judgment or for other relief.\n(b) A motion filed in apt time stays enforcement of the judgment.\u201d Ill. Rev. Stat. 1989, ch. 110, par. 2 \u2014 1203(a).\nRule 303(a) governs when the notice of appeal must be filed:\n\u201c(1) Except as [not relevant here], the notice of appeal must be filed with the clerk of the circuit court within 30 days after the entry of the final judgment appealed from, or, if a timely post-trial motion directed against the judgment is filed, whether in a jury or a nonjury case, within 30 days after the entry of the order disposing of the last pending post-trial motion.\u201d 134 Ill. 2d R. 303(a)(1).\nAndersen v. Resource Economics Corp. (1990), 133 Ill. 2d 342, 549 N.E.2d 1262, and Beck v. Stepp (1991), 144 Ill. 2d 232, 579 N.E.2d 824, are the two most recent supreme court opinions interpreting what constitutes a post-judgment motion for purposes of section 2\u2014 1203 and Rule 303(a)(1). In Andersen, plaintiff\u2019s second-amended complaint was dismissed on March 28, 1985. On April 26, 1985, plaintiff filed in the circuit court a notice of appeal seeking reversal of the circuit court\u2019s order of dismissal and reinstatement of his second-amended complaint. Later that same day, plaintiff filed a motion for leave to file a third-amended complaint. In his motion, plaintiff stated his intention to plead \u201cfurther allegations, new and distinct from the prior allegations,\u201d which would \u201cstate a theory substantively different from the prior allegations\u201d and \u201ccure any defect in the Second Amended Complaint.\u201d The motion alleged that the facts underlying the \u201cnew and distinct\u201d allegations were previously \u201cunknown to plaintiff\u2019s attorney.\u201d Andersen, 133 Ill. 2d at 344, 549 N.E.2d at 1263.\nPlaintiff subsequently moved to dismiss his appeal, claiming that his motion was \u201cin the nature of a post-trial motion.\u201d The circuit court granted dismissal of the appeal on July 23, 1985. On October 8, 1985, the circuit court denied plaintiff\u2019s motion. On November 6, 1985, plaintiff appealed the circuit court\u2019s March 28 and October 8 orders to the appellate court. Andersen, 133 Ill. 2d at 344, 549 N.E.2d at 1263-64.\nOn appeal, the appellate court addressed whether plaintiff\u2019s motion to file a third-amended complaint could be considered a valid post-trial motion. The appellate court ruled that it was and that plaintiff\u2019s motion tolled the time in which he was required to file a notice of appeal under Rule 303(aXl). Andersen, 133 Ill. 2d at 344, 549 N.E.2d at 1264.\nThe supreme court on review vacated the judgment of the appellate court, holding that plaintiff\u2019s motion for leave to amend was not a valid post-judgment motion. To support its holding, the court reasoned:\n\u201cIn Fultz v. Haugan (1971), 49 Ill. 2d 131, 135-36, this court held a motion for leave to amend a complaint, after dismissal with prejudice, does not extend the time for appeal or the time for filing other motions [citation], because such a motion is not \u2018directed against the judgment\u2019 within the meaning of Rule 303(aXl), nor is it encompassed within the relief provided for by section 68.3(1) of the Civil Practice Act (Ill. Rev. Stat. 1969, ch. 110, par. 68.3(1) (now Ill. Rev. Stat. 1987, ch. 110, par. 2\u2014 1203(a))), which specifies rehearing, retrial, modification or vacation of judgment, or \u2018other relief.\u2019 Fultz, 49 Ill. 2d at 135-36.\nThe purpose of a post-judgment motion is, after all, to allow the circuit court to review its decisions and, to that end, specificity is required. (Brown v. Decatur Memorial Hospital (1980), 83 Ill. 2d 344, 349-50.) Plaintiff\u2019s motion neither requests modification or vacation of the judgment, nor offers any points warranting such. Hence, it is not a valid post-judgment motion.\nEven if we were to disregard Fultz, which appears to be controlling authority, our examination of plaintiff\u2019s motion reveals that it is nothing more than a title and an ambiguous prayer for relief with absolutely no substance in between. To call such a document a \u2018post-judgment motion\u2019 would be to blindly adhere to nomenclature at the expense of reality. This we refuse to do.\u201d (Emphasis in original.) Andersen, 133 Ill. 2d at 347, 549 N.E.2d at 1264-65.\nIn Beck v. Stepp (1991), 144 Ill. 2d 232, 579 N.E.2d 824, plaintiff filed a personal injury action arising from an automobile accident against Stepp and Bob Brockland Pontiac GMC, Inc. Brockland filed for summary judgment, which the circuit court granted on April 6, 1988. On April 15, the court received a letter from plaintiff\u2019s counsel:\n\u201cOn Wednesday, April 6, the Court held a conference call with counsel for the parties pertaining to Brockland\u2019s Motion for Summary Judgment. I understood the Court to announce that it was denying the Motion, but the Order states that the Motion was allowed.\nThank you for your attention to this matter.\u201d\nCounsel sent a copy of the letter to both defense attorneys. Beck, 144 Ill. 2d at 236, 579 N.E.2d at 826.\nOn June 2, 1988, Brockland filed a special and limited appearance contesting the circuit court\u2019s jurisdiction over it and asking the court to decline to take any further action with respect to plaintiff\u2019s claim. The court subsequently entered a nunc pro tunc order amending the April 6 order to reflect that summary judgment was denied, not allowed. Beck, 144 Ill. 2d at 236-37, 579 N.E.2d at 826.\nBrockland appealed, and the appellate court dismissed the appeal. On further review, the supreme court addressed the issue of whether plaintiff\u2019s April 14 letter was in substance a post-judgment motion which permitted the court to alter its April 6 order granting Brock-land summary judgment. In holding the letter did not so qualify, the court stated the requirements of a section 2 \u2014 1203 post-judgment motion as follows:\n\u201cA post-judgment motion must include a request for at least one of the forms of relief specified in section 2 \u2014 1203. [Citations.] In addition, a post-judgment motion must allege grounds that would warrant the granting of the relief requested. (Andersen v. Resource Economics Corp. (1990), 133 Ill. 2d 342, 347.) Finally, a post-judgment motion must be filed with the clerk of the court, and copies of the motion must be served upon all parties. (134 Ill. 2d R. 104(b).)\u201d Beck, 144 Ill. 2d at 240, 579 N.E.2d at 828.\nDespite the absence of language in section 2 \u2014 1203 requiring specificity in post-judgment motions filed thereunder, Andersen and Beck have clearly grafted such a requirement onto section 2 \u2014 1203. We are without authority to deviate from the court\u2019s pronouncements. Nevertheless, we distinguish Andersen and Beck from the instant case. Andersen and Beck were faced with documents which could not reasonably be deemed post-judgment motions. In Andersen, the document in question was a motion for leave to file an amended complaint, while in Beck it was a personal letter to the court. Neither document requested the types of relief contemplated by either Rule 303(aXl) or section 2 \u2014 1203. Consequently, neither document could advance a ground to support relief which was not requested.\nIn this case, plaintiff\u2019s motion for reconsideration was entitled \u201cmotion for reconsideration\u201d and requested such relief. Thus, plaintiff\u2019s motion was the specie of document contemplated by Rule 303(aXl) and section 2 \u2014 1203.\nMore importantly, plaintiff\u2019s motion requested leave of court to file a supporting memorandum within 14 days of the hearing of the motion. While we know of no reason why plaintiff could not have included his grounds within the motion itself, we believe plaintiff satisfied Andersen\u2019s and Beck\u2019s requirement that specific grounds be alleged in post-judgment motions filed under section 2 \u2014 1203. Plaintiff directly requested leave of court to supply such grounds. Yet, subsequent to plaintiff\u2019s motion, the parties focused on the court\u2019s jurisdiction to hear plaintiff\u2019s motion, not the merits of the motion. This was in response to defendant\u2019s motion challenging such jurisdiction. When defendant\u2019s challenge came up for hearing on January 11, 1991, the court overruled defendant\u2019s objection, set a hearing date on the motion to reconsider and ordered that no further briefs be filed. The transcript of this hearing is not in the record. Thus, we do not know whether plaintiff then informed the court of the grounds supporting his motion. Plaintiff\u2019s motion for rehearing was subsequently denied.\nWe believe the above record serves to distinguish this case from Andersen and Beck on the matter of specificity. A substantial reason for the court in those cases to find the lack of a valid post-judgment motion was the moving party\u2019s failure to include any specificity in their respective \u201cmotions.\u201d Here, plaintiff\u2019s motion requested leave of court to supply such grounds. Subsequently, the court ordered that no further briefs be filed. When plaintiff\u2019s motion came up on the merits, relief was denied. Upon this record, we believe plaintiff satisfied the specificity requirement of Andersen and Beck. We accordingly find that plaintiff\u2019s motion for rehearing constituted a valid post-judgment motion, thereby tolling the time in which his notice of appeal was required to be filed under Rule 303(aXl). Having found jurisdiction, we turn now to plaintiff\u2019s argument that summary judgment was erroneously entered.\nSummary judgment shall be entered when \u201cthe pleadings, depositions, and admissions on file, together with the affidavits, if any, show that there is no genuine issue as to any material fact and that the moving party is entitled to a judgment as a matter of law.\u201d (Ill. Rev. Stat. 1987, ch. 110, par. 2 \u2014 1005(c).) While the use of the summary judgment procedure is to be encouraged as an aid in the expeditious disposition of a lawsuit, it is a drastic means of disposing of litigation and therefore should be allowed only when the right of the moving party is clear and free from doubt. Purtill v. Hess (1986), 111 Ill. 2d 229, 240, 489 N.E.2d 867, 871.\nIn determining the existence of a genuine issue of material fact, courts must consider the pleadings, depositions, admissions, exhibits, and affidavits on file in the case and must construe them strictly against the movant and liberally in favor of the opponent. (Purtill, 111 Ill. 2d at 240, 489 N.E.2d at 871.) Reviewing courts apply a de novo standard of review when determining the propriety of summary judgment. Shull v. Harristown Township (1992), 223 Ill. App. 3d 819, 585 N.E.2d 1164; Briggs Manufacturing Co. v. Industrial Comm\u2019n (1989), 212 Ill. App. 3d 318, 570 N.E.2d 1152; Demos v. National Bank of Greece (1991), 209 Ill. App. 3d 655, 567 N.E.2d 1083; General Motors Corp. v. Douglass (1990), 206 Ill. App. 3d 881, 565 N.E.2d 93.\nPlaintiff raises three arguments on appeal to advance his claim that summary judgment was improperly granted. First, while no party ever executed the written construction contract, the circuit court erred in finding that defendant was not bound by its terms where such contract reflects the parties\u2019 oral agreement. Second, defendant failed to comply with the written contract\u2019s technical requirements regarding performance and deviations therefrom. Third, a genuine issue of material fact exists on whether plaintiff and the architect \u201capproved defendant\u2019s disputed extracontractual undertakings.\u201d\nOn appeal, plaintiff makes much of the parties\u2019 alleged written contract. We assume for purposes of this appeal that the parties conformed their conduct to the written contract. We believe, however, this is of no aid to plaintiff.\nIt has long been Illinois law that strict adherence to a contract\u2019s technical requirements may be waived. (E.g., Chicago & Eastern Illinois R.R. Co. v. Moran (1900), 187 Ill. 316, 58 N.E. 355.) With regard to waiver, we stated in Whalen v. K mart Corp. (1988), 166 Ill. App. 3d 339, 343, 519 N.E.2d 991, 994, the following:\n\u201cParties to a contract have the power to waive provisions placed in the contract for their benefit and such a waiver may be established by conduct indicating that strict compliance with the contractual provisions will not be required. [Citation.] An implied waiver of a legal right may arise when conduct of the person against whom waiver is asserted is inconsistent with any other intention than to waive it. [Citation.]\nWaiver is either an express or implied voluntary and intentional relinquishment of a known and existing right. [Citation.] The determination as to what facts are sufficient to constitute waiver is a question of law. [Citation.] An analysis of whether there was in fact a waiver of contractual provisions focuses on the intent of the nonbreaching party. If he has intentionally relinquished a known right, either expressly or by conduct inconsistent with an intent to enforce that right, he has waived it and may not thereafter seek judicial enforcement.\u201d\nIn this case, the facts are undisputed that the rubbled condition of the property was a known fact by both parties. Rather than address the problem initially, the parties agreed to address it later in the project when the true extent of the problem was discovered. A meeting was subsequently held to address the problem, and a solution was chosen. Defendant implemented the solution, and plaintiff and his architect watched as defendant worked. Upon completion of the project, plaintiff\u2019s architect issued a certificate of substantial completion.\nWe believe the above facts preclude plaintiff from now claiming that the changes required by the property\u2019s rubbled condition must have been in writing. Clearly, if plaintiff wished for the contract\u2019s technical requirements to have been met, it was incumbent upon plaintiff to demand them prior to defendant\u2019s commencement of the foundation work. Failing defendant\u2019s compliance with such demand, plaintiff could stop the project. Plaintiff\u2019s failure to undertake such conduct constitutes a waiver of the contract\u2019s formal requirements. See also Delta Construction, Inc. v. Dressler (1978), 64 Ill. App. 3d 867, 381 N.E.2d 1023; Mayer Paving & Asphalt Co. v. Carl A. Morse, Inc. (1977), 48 Ill. App. 3d 73, 365 N.E.2d 360; W.H. Stubbings Co. v. World\u2019s Columbian Exposition Co. (1903), 110 Ill. App. 210.\nWe next address plaintiff\u2019s argument that a triable issue exists as to whether he and his architect approved defendant\u2019s handling of the excavation problem. We find plaintiff\u2019s argument unpersuasive.\nPlaintiff\u2019s architect testified in his deposition that he attended the meeting at which options were discussed relative to handling the rub-bled condition of the property. Plaintiff also attended. While plaintiff asserts in his affidavit that his architect did not attend, he qualifies this assertion by stating that such nonattendance was only \u201cto the best of his recollection.\u201d In any event, defendant sent a letter to plaintiff and his architect dated October 11, 1984, which memorialized the agreement. Plaintiff\u2019s architect testified that if a better solution existed to treat the rubbled condition, he would have recommended it.\nThe undisputed facts show that plaintiff and his architect approved defendant\u2019s handling of the rubbled condition of the property. While plaintiff states in his affidavit that he relied on defendant to make the decision in question and that he has no expertise in such areas, plaintiff and his architect nevertheless allowed defendant to proceed with construction. Again, had plaintiff sought technical compliance with the contract, he should have asked. We do not believe plaintiff can recover damages against defendant where defendant did exactly what plaintiff and his architect approved him to do.\nFor the above reasons, summary judgment in favor of defendant was proper. Given the result we reach on this issue, we decline to address defendant\u2019s res judicata argument.\nWe next address plaintiff\u2019s argument that the circuit court erred in denying him leave of court to file a third-amended complaint. After the court orally indicated it would grant summary judgment to defendant, plaintiff orally moved to amend his complaint to assert that defendant failed to perform the excavation work in a workmanlike manner. In denying plaintiff leave to amend, the court recognized that it had authority to permit the amendment pursuant to section 2\u2014 1005(g) of the Code of Civil Procedure (Ill. Rev. Stat. 1987, ch. 110, par. 2 \u2014 1005(g)), but because no testimony supported plaintiff\u2019s new theory, it would decline plaintiff\u2019s request. When plaintiff moved for reconsideration, he limited his motion to the court\u2019s grant of summary judgment. The denial of leave to amend was not addressed. The hearing on plaintiff\u2019s motion for reconsideration was similarly limited to the summary judgment grant. Plaintiff at no time ever submitted a third-amended complaint to the circuit court, and no such complaint is in the record.\nRegardless of whether we treat plaintiff\u2019s attempt to amend as brought pursuant to section 2 \u2014 616(a) of the Code of Civil Procedure, which permits amendments \u201c[a]t any time before final judgment *** on just and reasonable terms\u201d (Ill. Rev. Stat. 1989, ch. 110, par. 2\u2014 616(a)), or under section 2 \u2014 1005(g), which permits amendments \u201c[b]e-fore or after the entry of a summary judgment *** upon just and reasonable terms\u201d (Ill. Rev. Stat. 1989, ch. 110, par. 2 \u2014 1005(g)), our inquiry is the same: whether the circuit court abused its discretion in denying leave to amend. (Loyola Academy v. S & S Roof Maintenance, Inc. (1992), 146 Ill. 2d 263, 586 N.E.2d 1211.) This determination requires us to evaluate the following four factors established to address this issue in Kupianen v. Graham (1982), 107 Ill. App. 3d 373, 437 N.E.2d 774, and adopted by our supreme court (see Loyola Academy, 146 Ill. 2d at 273, 586 N.E.2d at 1215-16): (1) whether the proposed amendment would cure the defective pleading; (2) whether other parties would sustain prejudice or surprise by virtue of the proposed amendment; (3) whether the proposed amendment is timely; and (4) whether previous opportunities to amend the pleading could be identified.\nUnder the first element, plaintiff\u2019s failure to tender his third-amended complaint or include it in the appellate record significantly diminishes our ability to determine whether the proposed amendment would provide plaintiff with a viable theory against defendant. Indeed, as defendant argues, plaintiff\u2019s omissions constitute a waiver in this court of plaintiff\u2019s right to have the denial of leave to amend reviewed. (Enblom v. Milwaukee Golf Development (1992), 227 Ill. App. 3d 623, 592 N.E.2d 190.) Aside from waiver, on appeal, plaintiff alleges that, \u201csince the defendant\u2019s work was completed, the plaintiff has suffered ongoing, unnatural settlement and subsidence problems in certain areas of his shopping center.\u201d From this fact, plaintiff asserts that a fair inference exists that defendant failed to perform its contractual obligations in a workmanlike manner.\nWe will not speculate as to whether defendant satisfactorily performed its contractual obligations. It was incumbent upon plaintiff to file with the circuit court the amended complaint containing facts supporting his new theory of recovery. The mere fact of subsidence is neutral in this case in light of the rubbled condition of the property when the construction began. Without supporting facts, plaintiff\u2019s theory of recovery is nothing more than that, a theory. Plaintiff has accordingly failed to show that an amendment to the pleadings would cure the defect in his case. See Regas v. Associated Radiologists, Ltd. (1992), 230 Ill. App. 3d 959, 595 N.E.2d 1223; In re Estate of Hopkins (1991), 214 Ill. App. 3d 427, 574 N.E.2d 230; Wingate v. Camelot Swim Club, Inc. (1990), 193 Ill. App. 3d 963, 550 N.E.2d 665 (all refusing to allow amendment where it would not cure pleading defect).\nWe consider the second and third elements together. Plaintiff commenced this action on March 20, 1989. Plaintiff filed an initial complaint and two amended complaints. None of these complaints pursued a misperformance theory; however, plaintiff did assert a negligence theory which was subsequently dismissed. Discovery then ensued, including the deposition of plaintiff\u2019s architect. Following this deposition, defendant wrote plaintiff seeking to obtain a voluntary dismissal based on the architect\u2019s testimony. Plaintiff declined and filed no amended complaint. On October 24, 1990, the court awarded summary judgment to defendant, some 18 months after this action was initiated.\nIt is clear that plaintiff had ample opportunity to change theories, yet chose otherwise. Defendant undertook discovery and defended against plaintiff\u2019s action under one theory. To now allow plaintiff to haul defendant into court again under a different theory would prejudice defendant. This case is beyond the pleading stages. We distinguish on this ground the cases which have permitted amendment under section 2 \u2014 1005(g) because the amendment was sought in the pleading stages. See Loyola Academy, 146 Ill. 2d 263, 586 N.E.2d 1211; Giacalone v. Chicago Park District (1992), 231 Ill. App. 3d 639, 596 N.E.2d 731; Evans v. United Bank (1992), 226 Ill. App. 3d 526, 589 N.E.2d 933.\nRegarding timing, while 17 months from when a suit is filed has been held to be a reasonable time in which to seek an amendment (Loyola Academy, 146 Ill. 2d 263, 586 N.E.2d 1211), and while plaintiff's proposed amendment here occurred at 18 months, it again must be noted that this case is beyond the pleading stages. Also, plaintiff has offered no explanation for his failure to include a claim for misperformance. Plaintiff\u2019s failure is particularly significant here because the subsidence problems are not latent. When plaintiff\u2019s negligence count was dismissed previously, plaintiff could have easily amended his complaint to pursue a contract theory alleging unworkmanlike performance. Plaintiff did not do so.\nThe final element is whether plaintiff ever attempted his amendment previously. As noted, plaintiff has already amended his complaint twice before. Thus, he has had opportunity to add the proposed amendment. (Compare Loyola Academy, 146 Ill. 2d 263, 586 N.E.2d 1211; Giacalone, 231 Ill. App. 3d 639, 596 N.E.2d 731; Evans, 226 Ill. App. 3d 526, 589 N.E.2d 933 (proposed amendment was first real opportunity to amend), with Pegas, 230 Ill. App. 3d 959, 595 N.E.2d 1223 (plaintiff had amended two times before).) For these reasons, we affirm the circuit court\u2019s denial of plaintiff\u2019s motion to amend his complaint.\nRegarding defendant\u2019s cross-appeal, we affirm the denial of sanctions. Plaintiff\u2019s theory of recovery was defective from the start. All the parties knew of the rubbled condition of the property and delayed addressing the foundational problems caused thereby until a clearer picture of the problem existed. When that time came, a meeting was held at which the owner was presented with various alternatives. The one selected and approved by the owner allowed the project to proceed without excessive cost or delay.\nOn appeal, plaintiff asserts that his approval was not a knowing approval; he lacked construction expertise. Thus, he relied on defendant\u2019s expertise and recommendations in approving the foundation work. Plaintiff\u2019s theory of recovery in this case posits that the traditional roles of an architect, owner and general contractor in the typical construction setting were eroded. Plaintiff theorizes that while normally, a general contractor will not be liable for properly performing the contract in accordance with the architect\u2019s specifications, the contractor is liable where it assumes the role of both architect and contractor. Where following such an assumption of duty construction defects occur, the contractor is liable for such defects even where the contractor performs in a workmanlike manner.\nOur review of plaintiff\u2019s briefs reveals no authority to support his theory or recovery. Even the facts weigh heavily against plaintiff. The undisputed record shows approval of defendant\u2019s conduct by both plaintiff and his architect. While plaintiff asserts such approvals were not informed, they occurred nonetheless.\nNotwithstanding the above discussion, we must affirm the denial of sanctions. The circuit court was presented with plaintiff\u2019s theory and the facts he marshalled to support it. The court exercised its discretion in denying sanctions, and we defer to its ruling. This case was not brought in bad faith as plaintiff apparently has suffered and will continue to suffer unnatural settling. A cause of action may have existed against someone; however, it is not against defendant under the theory presented. We defer to the circuit court\u2019s determination that sanctions are unwarranted in this case.\nFor the foregoing reasons, the judgments of the circuit court of Cook County granting summary judgment and denying sanctions are affirmed.\nAffirmed.\nCAMPBELL and O\u2019CONNOR, JJ., concur.", "type": "majority", "author": "PRESIDING JUSTICE BUCKLEY" } ], "attorneys": [ "Katz, Randall & Weinberg, of Chicago (Jeffrey H. Bunn, of counsel), for appellant.", "Beermann, Swerdlove, Woloshin, Barezky, Becker, Genin & London, of Chicago (Alvin R. Becker and Timothy M. Kelly, of counsel), for appellee." ], "corrections": "", "head_matter": "ARTHUR B. MENDELSON, Plaintiff-Appellant and Cross-Appellee, v. BEN A. BORENSTEIN AND COMPANY, Defendant-Appellee and Cross-Appellant.\nFirst District (1st Division)\nNo. 1 \u2014 91\u20140645\nOpinion filed December 14, 1992.\nKatz, Randall & Weinberg, of Chicago (Jeffrey H. Bunn, of counsel), for appellant.\nBeermann, Swerdlove, Woloshin, Barezky, Becker, Genin & London, of Chicago (Alvin R. Becker and Timothy M. Kelly, of counsel), for appellee." }, "file_name": "0605-01", "first_page_order": 623, "last_page_order": 639 }