{ "id": 2510632, "name": "Patrick C. Boylan v. William A. Cameron", "name_abbreviation": "Boylan v. Cameron", "decision_date": "1906-05-07", "docket_number": "Gen. No. 12,472", "first_page": "432", "last_page": "439", "citations": [ { "type": "official", "cite": "126 Ill. App. 432" } ], "court": { "name_abbreviation": "Ill. App. Ct.", "id": 8837, "name": "Illinois Appellate Court" }, "jurisdiction": { "id": 29, "name_long": "Illinois", "name": "Ill." }, "cites_to": [ { "cite": "185 Ill. 179", "category": "reporters:state", "reporter": "Ill.", "year": 1895, "opinion_index": 0 }, { "cite": "203 Ill. 202", "category": "reporters:state", "reporter": "Ill.", "opinion_index": 0 }, { "cite": "101 Ill. 68", "category": "reporters:state", "reporter": "Ill.", "opinion_index": 0 }, { "cite": "158 Ill. 195", "category": "reporters:state", "reporter": "Ill.", "opinion_index": 0 }, { "cite": "208 Ill. 382", "category": "reporters:state", "reporter": "Ill.", "opinion_index": 0 }, { "cite": "46 Ill. 250", "category": "reporters:state", "reporter": "Ill.", "opinion_index": 0 } ], "analysis": { "cardinality": 640, "char_count": 13777, "ocr_confidence": 0.538, "pagerank": { "raw": 2.1540046093849544e-07, "percentile": 0.768991937367777 }, "sha256": "017632326eb54895d01d45141a8b496f19e64d640823662e840aa9ed8ecdc077", "simhash": "1:2f1526f6db2a9cf0", "word_count": 2397 }, "last_updated": "2023-07-14T16:06:21.343946+00:00", "provenance": { "date_added": "2019-08-29", "source": "Harvard", "batch": "2018" }, "casebody": { "judges": [], "parties": [ "Patrick C. Boylan v. William A. Cameron." ], "opinions": [ { "text": "Mr. Justice Ball\ndelivered the opinion of the court.\nWe are compelled to affirm the decree of the trial court for the following reasons:\nFirst. The allegations of the cross-bill of plaintiff in error and the proofs do not correspond. ' It is alleged in the cross-bill as amended December 7, 1903, that the contract on which he bases his claim for a lien, as entered into between him and the Central Brick & Stone Co., was a verbal contract. The evidence shows that the parties met June 1, 1900, and then agreed upon the terms of a contract. The next day they met again by appointment and then entered into the written contract which is set out in the statement of facts. Yerbal evidence as to what was said or agreed to before the contract was given is inadmissible to change or to vary a written agreement. Such evidence cannot be received to strike out or to add any clause to a written contract. All prior negotiations are merged in the written instrument. Marshall v. Gridley, 46 Ill. 250; Davis v. Fidelty Fire Ins. Co., 208 Ill. 382. It follows that the only competent evidence in the record of the agreement of the parties is the written instrument, and with that instrument in evidence we cannot look to the conversation they had prior to its execution, and therefore the repugnance between allegation and proof is so great as to prevent a recovery. A party complainant cannot avail himself of any fact established by the evidence which is not alleged in his bill. He is not permitted to state one case in the bill and to make out a different one in proof. Adams v. Gill, 158 Ill. 195. Further, the master struck out the evidence of Boylan as to this verbal contract when it appeared that there was a written contract. Counsel for Boylan asked the master to certify that ruling to the court, to which the master assented. We are unable to find in the record that the court was ever asked to pass upon this question, or that the evidence thus excluded was again offered. It follows that such evidence is not before us, and that the allegation that the parties entered into a verbal contract is not sustained by testimony.\nSecond. W hile the decree recites that the exceptions to the master\u2019s reports filed by Boylan are overruled, we find no exceptions in the abstract, nor do we find an order permitting the objections filed before the master to stand as exceptions to those reports, or to either of them. In the absence of such exceptions we do not know what the court overruled, and therefore must presume that the decree in that particular is correct.\n\u201cExceptions to the report of masters are in the nature of special demurrers, and the party objecting must point out the error; otherwise the part not excepted to will be taken as admitted.\u201d 1 Barb. Ch. Pr. (ed. 1843) 191.\nWhere the master overrules the objections filed to his report, it is the duty of the objecting party after such report has been filed in court to appear there and file exceptions to it; and when this course has not been pursued, and no sufficient reason is assigned for not doing so, the report of the master, when approved by the court, will be deemed in the appellate tribunal conclusive upon the questions covered by it. Jewell v. Rock River P. Co., 101 Ill. 68.\nThe exception to this rule is where the master correctly states the facts, but draws an incorrect legal conclusion therefrom. In such case the court, taking the facts stated by the master to be true, will hear the objecting parties upon the question of -law without the filing of an exception thereto. Von Platen v. Winterbotham, 203 Ill. 202. The case at bar does not come within that exception.\nThird. Plaintiff in error did not commence his suit within the time prescribed by the lien law. \u201c The remedy by a mechanic\u2019s lien is cumulative to the ordinary remedy given by the common law, and is a privilege enjoyed by one class of. the community above all other classes; and, therefore, a party seeking to enforce it must bring himself strictly within the terms of the statute. Nothing can be inferred in his favor, but the law must be strictly construed.\u201d Freeman v. Rinaker, 185 Ill. 179. Confessedly, Boylan was a subcontractor. He testified that he completed his contract July 17,1900, and that the money therefor then became due. Section 34, chapter 82 (Act of 1895) provides: \u201cNo petition shall be filed or suit commenced to enforce the lien created by sections 22 and 23 (relating to subcontractors), unless the same is commenced within four months after the time that the final payment is shown to be due the subcontractor, * * * ; provided, if any delay in filing such petition or commencing suit is caused in consequence of the final payment not being due the contractor, the time of such delay shall not be reckoned.\u201d This section called upon Boylan to begin his suit within four months from July 17, 1900, if he wished to have the benefit of the act. This privilege expired November 17, 1900. His cross-bill, in the form of an answer, was not filed until December 20, 1900. Clearly this was too late. He cannot take advantage of the proviso, for the reason that the master found that he was not delayed in bringing his suit for a lien on said premises in consequence of the final payment not being due the contractor; to which finding of fact he took no objection before the master and filed no exception before the chancellor. Therefore, such finding, having been approved by the trial court, is conclusive upon Boylan upon this writ of error.\nThe decree of the Circuit Court is affirmed.\nAffirmed.", "type": "majority", "author": "Mr. Justice Ball" } ], "attorneys": [ "Patrick C. Boylan, plaintiff in error, per se.", "J. S. Dudley, for defendant in error." ], "corrections": "", "head_matter": "Patrick C. Boylan v. William A. Cameron.\nGen. No. 12,472.\n1. Contracts\u2014parol evidence not competent to vary. Parol evidence is not competent to change or to vary the terms of a written instrument, and all prior negotiations are merged in the written instrument.\n2. Allegations and proof\u2014effect of failure to correspond. A party complainant cannot avail himself of any fact established by the evidence which is not alleged in the bill; he is not permitted to state one case iii the bill and to make out a different one in the proof.\n3. Master\u2019s report\u2014what does not show filing of exceptions to. A recital contained in the decree to the effect that exceptions filed were overruled, does not supply the absence of exceptions from the record.\n4. Master\u2019s report\u2014when exceptions to, essential to review, when not. Exceptions are essential to review the report of a master, except where he correctly states the facts, but draws an incorrect legal conclusion from them.\n5. Mechanic's lien\u2014must be brought within time fixed by statute. A proceeding by which a mechanic\u2019s lien, is sought to be enforced must be instituted within the time fixed by statute or such proceeding will fail, and this rule applies where the proceeding is by cross-bill interposed in an action brought by another party.\nForeclosure proceeding with cross-bill seeking mechanic\u2019s lien. Error to the Circuit Court of Cook County; the Hon. John L. Healt,\nJudge, presiding. Heard in this court at the October term, 1905.\nAffirmed.\nOpinion filed May 7, 1906.\nAffirmed.\nRehearing denied May 21, 1906.\nStatement Tby the Court. November 8,1900, the Northern Trust Company, trustee, filed three separate bills to foreclose certain trust deeds upon lots six, seven and eight, respectively, in Sidney A. Kent\u2019s subdivision, etc., in Cook county, Illinois. Shortly thereafter these cases were consolidated. Boylan, who was made a party defendant, filed his answer in the nature of an intervening petition under the mechanic\u2019s lien law December 20, 1900. In this answer Boylan charges, among other things, that June 2,1900, he entered into a written contract with the Central Brick & Stone Co. to do the gasfitting of an apartment building then being erected on these lots for the sum of $320, payable when said work was completed; that said premises were owned by one Annie Connell, who had theretofore entered into a contract with said Central Brick & Stone Co. for the erection of said apartment building on said premises, to be completed and paid for before- the end of the year 1900; that he, Boylan, completed his contract July 16, 1900, and the sum of $320 became then due him; that August 5, 1900, he served written notice of his*claim upon said Connell, who was then indebted to said Central Brick & Stone Co. in an amount greater than $320; that August 6, 1900, he filed in the office of the clerk of the Circuit Court a written statement of his claim; that December 18, 1900, he amended said claim by adding thereto a copy of the contract between himself and the Central Brick & Stone Co. The prayer is for a lien and an accounting, etc.\nMay 7, 1901, Boylan filed an amended answer and intervening petition in said consolidatd cause, seeking a mechanic\u2019s lien for the same work and amount, but declaring that the contract between him and the Central Brick & Stone Co. was \u201c a partly written and verbal contract,\u201d and asserting that said premises were then owned by said Connell and one Eli A. Gage.\nDecember 7, 1903, Boylan procured leave to amend this last mentioned pleading by striking out the name of Annie Connell, thus leaving the title to said premises in said Gage, and by substituting the name of Gage for that of Connell in the notice served August 4, 1900, and by striking out of the description-of the contract between himself and the Central Brick & Stone Co. the words \u201c partly written and,\u201d so that it shall read \u201c a verbal contract was made and entered into,\u201d etc.\nIn the meantime Cameron had become the owner of the property. He was made a party in said cause, and filed his answer to Boylan\u2019s petition June 8, 1901, in which he denied everything, except that he was the owner of the premises.\nThe issues were made up and the cause was referred to a master to take proofs and to report his findings of fact and of law. The master took the testimony and filed his report January 23, 1903. From that report it appeared that October 11, 1901, Boylan testified, among other things, that he talked about putting the gasfittings into said building with McSorley, the president of the Central Brick & Stone Co., June 1, 1900, and that in that conversation the terms and conditions of a contract for that purpose were agreed upon between them, by which the work was to be started June 4, 1900, and to be finished July 15, 1900; that the next day, by appointment, he went to MeSorley\u2019s office, and there the following contract was entered into:\n\u201cJune 2, 1900.\nThis agreement, made by and between P. C. Boylan, party of the first part, and Central Brick & Stone Company, party of the second part, both of the City of Chicago, County of Cook and State of Illinois; Witnesseth, That for the consideration of three hundred and twenty ($320) dollars, said party of the first part agrees to do the gas-fitting of the building 5420-28 Indiana avenue, as per plans and specifications, said second party furnishing all gas pipe, fittings and tools, and for the performance of the above-mentioned work said second party agrees to pay to said first party three hundred and twenty ($320) dollars when said work is completed. It is further agreed that said first party shall push the work so as not to delay other workmen.\nP. C. Boylan.\u201d\n\u25a0 He further testified that he completed said work July IB, 1900, and that the next day it was inspected and accepted by the gas company; that there was then due him the sum of $320, and that he gave the certificate of inspection within a week afterwards to McSorley, who said it was all right; that the roof was on the building July 17, 1900, but after that there were delays and the building was not completed until about March 1, 1901.\nThe evidence further shows that Gage was the owner of said premises December 12, 1899, when he entered into the contract with the Central Brick & Stone Co. for the erection of the building; that Boylan served a subcontractor\u2019s notice on Gage August 4,1900; that Cameron became the owner of these premises by deed dated December 12, 1900; that the Central Brick & Stone Co. abandoned the building in an .unfinished condition November 23,1900; and that thereafter Cameron completed the same at his own cost. The master found that Boylan had been paid $46.50 upon his claim, and that the evidence did not show that Boylan was delayed in the bringing of his suit in consequence of the final payment not being due the contractor. The master found in conclusion that the claim of Boylan for a lien upon said premises should be denied: * * * \u201cThirdly, because suit was not commenced to enforce' said lien within four months after final payment was due him.\u201d\nBoylan filed objections to the master\u2019s report, which were considered and overruled.\nAfterwards the hearing of the ease was re-opened to let in certain testimony for the Central Lumber Co., one of the defendants, and a supplemental report was filed by the master January llj 1905, in which, as to Boylan, the findings in the original report were adhered to, except that the first reason given for finding against Bovlan\u2019s claim for lien, namely, that the written contract between the Central Brick & Stone Co. and Boylan \u201cdid not stipulate the time for the completion of the work or time for payment,\u201d was eliminated. To this last report Boylan filed exceptions, which were overruled.\nMarch 21, 1905, a decree was entered overruling the exceptions filed by Boylan to the master\u2019s report, and approving and confirming such report, and dismissing the cross-bill of said Boylan as amended for want of equity, and adjudging the costs of suit, including $32 solicitor\u2019s fees, against him. From this decree the present writ of error was sued out.\nPatrick C. Boylan, plaintiff in error, per se.\nJ. S. Dudley, for defendant in error." }, "file_name": "0432-01", "first_page_order": 450, "last_page_order": 457 }