{ "id": 2521402, "name": "Concord Apartment House Co. v. W. D. O'Brien et al.", "name_abbreviation": "Concord Apartment House Co. v. O'Brien", "decision_date": "1906-10-08", "docket_number": "Gen. No. 12,605", "first_page": "437", "last_page": "446", "citations": [ { "type": "official", "cite": "128 Ill. App. 437" } ], "court": { "name_abbreviation": "Ill. App. Ct.", "id": 8837, "name": "Illinois Appellate Court" }, "jurisdiction": { "id": 29, "name_long": "Illinois", "name": "Ill." }, "cites_to": [ { "cite": "104 Ill. App. 5", "category": "reporters:state", "reporter": "Ill. App.", "case_ids": [ 2584361 ], "opinion_index": -1, "case_paths": [ "/ill-app/104/0005-01" ] }, { "cite": "199 Ill. 294", "category": "reporters:state", "reporter": "Ill.", "case_ids": [ 3263633 ], "opinion_index": 0, "case_paths": [ "/ill/199/0294-01" ] }, { "cite": "153 Pa. St. 123", "category": "reporters:state", "reporter": "Pa.", "case_ids": [ 840389 ], "opinion_index": 0, "case_paths": [ "/pa/153/0123-01" ] }, { "cite": "92 Ill. 559", "category": "reporters:state", "reporter": "Ill.", "case_ids": [ 2739653 ], "opinion_index": 0, "case_paths": [ "/ill/92/0559-01" ] }, { "cite": "84 Ill. 225", "category": "reporters:state", "reporter": "Ill.", "case_ids": [ 2650563 ], "opinion_index": 0, "case_paths": [ "/ill/84/0225-01" ] }, { "cite": "144 Ill. 132", "category": "reporters:state", "reporter": "Ill.", "case_ids": [ 3078989 ], "opinion_index": 0, "case_paths": [ "/ill/144/0132-01" ] }, { "cite": "104 Ill. App. 5", "category": "reporters:state", "reporter": "Ill. App.", "case_ids": [ 2584361 ], "opinion_index": 0, "case_paths": [ "/ill-app/104/0005-01" ] } ], "analysis": { "cardinality": 784, "char_count": 18430, "ocr_confidence": 0.48, "pagerank": { "raw": 1.0906553016013182e-07, "percentile": 0.5655526634950532 }, "sha256": "cd9e03410a431785c29f44081bb36a1ee5ae302cca08d668ff93f619367c67ee", "simhash": "1:e8cf47fab03fb0b8", "word_count": 3120 }, "last_updated": "2023-07-14T19:13:56.609878+00:00", "provenance": { "date_added": "2019-08-29", "source": "Harvard", "batch": "2018" }, "casebody": { "judges": [], "parties": [ "Concord Apartment House Co. v. W. D. O\u2019Brien et al." ], "opinions": [ { "text": "Mr. Justice Holdom\ndelivered the opinion of the court.\nHaving in view Sedgwick v. Concord Apartment House Co., 104 Ill. App. 5, it only remains for this court to now determine whether the proof in the record, when tested by legal principles applicable to it, sustains the decree.\nIt is apparent that the written contract of May 28, 1895, between appellant and W. D. O\u2019Brien, as enlarged by the following indorsement thereon in writing: \u201cDecember 21, 1895. We hereby agree to pay said first party the additional sum of $1,500, same being for increased cost of material to be used in the building.\u201d Signed, \u201cThe Concord Apartment House Company,\nBy Cabl Findelsen, President,\nA. A. Bole, Secretary.\u201d\nforms the contract by which the rights of the contestants here must be determined. This is patent from the fact that no further specification was made at the time of the indorsement above set forth. None was necessary under the conditions in which the parties then were. The failure of O\u2019Brien to commence the construction of the building as provided by the original contract, resulted through no fault of his, but for the reason obvious from the proofs, that appellant was without money to finance the enterprise. That the fault did not lay with O\u2019Brien is evident from the further fact that appellant recognized that the cost of material had enhanced between May 28, 1895, and December 21, 1895, and for which $1,500 was added to the contract price. The contract was thereby revived and remained in full force, with this difference only, that $1,500 was added to the contract price. That writing\u2019 was also in effect an admission that the delay in starting the building was not chargeable to O\u2019Brien. Whether or not this delay may be accounted for by the uncontradicted testimony of the secretary of appellant, Rolf, that \u201cthe company had no money except at one time $500 received from the railroad company for assigning frontage on Indiana A'denue,\u201d is not necessary at this time for us to decide, but that the delay was caused by appellant is clear.\nBy . article V of the cqntract it is provided that all work contemplated by the contract shall be done and completed on or before September 15, 1895, and by article VI all delays by the owner or superintendent or resulting from other causes without the fault of the contractor, the time for completion shall be extended for a period equivalent to the time so lost, and by article VII final payment, it is provided, shall be made within thirty days after completion of the work.\nTime for final completion and payment is so certainly fixed by the contract as to fully comply with the essential statutory requirements preliminary to establishing a mechanic\u2019s lien.\nThe amount found due by the decree can be sustained under two conditions deducible from the evidence.\nFirst. By the terms of the contract Wheatley, the architect, was constituted the final arbiter as to the amounts due O \u2019Brien under the contract, and all such amounts were to be paid on his certificate. By article IX the final certificate of the architect was made binding and conclusive on all parties.\nSecond. There was an accounting made by 0 \u2019Brien with Rolf, the secretary, and Wheatley, the architect of appellant, as to the amount due. In which accounting all the counter-claims of appellant, together with the amounts paid on account of the contract, were gone over and an adjustment made and the amount due O\u2019Brien fixed at $4,568, for which sum Wheatley issued to O \u2019Brien a final certificate. Rolf also made and delivered to O\u2019Brien the following certificate:\n\u201cChicago, February 18, 1898.\nThis is to certify that a final certificate of $4,568 was issued by the Concord Apartment House Company in favor of W. D. 0 \u2019Brien, August 10,' 1896.\nA. A. Rolf, Secy. \u2019 \u2019\nNo fraud or mistake is either charged or proven in the settling of the account or in the issuing of the certificate by Wheatley, the bona fides of no one concerned in bringing about this ' result is challenged. Appellees might well have rested their primal proof at this stage. They had made out at least a prima facie case which, if subject to attack, the onus of so doing devolved upon appellant. The rights of the parties, in the absence of fraud or mistake, must under the rulings of the courts in this state be determined by the architect\u2019s certificate.\nAs was said in Arnold v. Bournique, 144 Ill. 132, on page 139, \u201cThe decision of the architects reduced to writing and signed by them, was the substantial act which determined the rights of plaintiffs to the money and determined the .obligation of the defendant to pay.\u201d\nAnd in Lull v. Korf, 84 Ill. 225, the same legal effect was given to the architect\u2019s certificate and the owner was held to be estopped thereby to urge defects in the work. The architect\u2019s certificate was held conclusive, unless it be shown the certificate is the offspring of fraud or mistake \u201cconnected with the issuing or the obtaining of such certificate.\u201d Appellees went farther and proved by Bolf, the secretary of appellant, every item entering into the certificate, and the fact of its having been made out and delivered by Wheatley to O\u2019Brien. Bolf was personally cognizant of the facts and competent to testify. The certificate of Wheatley was lost. Proof of this fact, as also its contents, was made by Bolf. We find no evidence in in the record in contradiction. Undisputed it is sufficient. Appellant has failed to prove that any of the orders, notes, acceptances and payments made and issued to material men for material furnished for the building to O\u2019Brien were so done after the accounting or the issuing of the certificate by Wheatley, nor can we gather from the evidence that such is the fact. The record is likewise silent as to any payment having been made by either appellant or Dickinson upon the judgment of the American Radiator Company v. W. P. Dickinson for $1,246.08, which judgment was for radiators put into the building of appellant by the American Badiator Company for O\u2019Brien, which O\u2019Brien was to supply under his contract with appellant. 0 \u2019Brien, for aught the record shows to the contrary, is still liable to the American Badiator Company for the value of such radiators. No advantage has accrued to him by reason of the judgment against Dickinson, and it would be inequitable to charge \"this amount against the certificate. The onus of proving payment, in whole or in part of the Dickinson judgment, was on appellant.\nIt is also contended that under the contract O \u2019Brien cannot maintain any action for a mechanic\u2019s lien and that the condition in the contract that O\u2019Brien should furnish whenever requested a release from any liens or rights of liens, is a complete and effectual waiver of the right to a mechanic\u2019s lien. Such condition is not susceptible to this construction. All that was intended by this condition was to protect the property of appellant from all liens which might accrue to subcontractors, material men, mechanics or laborers, for work, labor or materials done or furnished to the property of appellant under the 0 \u2019Brien contract, and was neither intended to, nor does the condition affect the right of 0 \u2019Brien to a lien for work and materials furnished by him under his contract. The covenant of O\u2019Brien was, in legal effect, to furnish upon request a release of the liens of third parties. Nor could any complaint be heeded of a failure to furnish such releases to appellant, if the failure of appellant to make payments at the times provided by the contract to the contractor O\u2019Brien was the cause and only reason why 0 \u2019Brien was unable to furnish releases of third parties at the time when any such releases were demanded; nor does the record in fact disclose any demand for releases other than contained in the answer, coupled with a demand that the intervening petition be dismissed. Downey v. O\u2019Donnell, 92 Ill. 559.\nThe decisions cited in which liens were held to be waived are grounded upon the express covenant by the contractor in unequivocal terms waiving the Tien. There is no such covenant found in the contract in question affecting the right of O\u2019Brien to a lien. If the parties had so intended, they would have made it evident by their contract. To be effective, there must be am express covenant or a covenant resulting by implication from the language used, so plain that a mechanic could so understand without seeking a professional interpretation as to its legal effect. Nice v. Walker, 153 Pa. St. 123.\nAdmitting that the taking of security for payments due under a building contract operates as a waiver of a statutory lien and is effective to discharge such lien of the recipient of such other security, and conceding that the record discloses that O\u2019Brien took many such securities in the nature of guaranties, checks, notes and moneys from W. P. Dickinson & Co., a third party, who in fact undertook to finance the building project by disposing of $150,000 of bonds issued by appellant, and that so far as these securities extended to pay sums due under the contract, the right to a statutory lien was discharged as to those sums; yet the right of O\u2019Brien to a mechanic\u2019s lien for the amount due on the final certificate of the architect \"Wheatley remains unaffected, in the absence of any claim or proof that such other securities or payments were made or received for or on account of the amount certified by Wheatley to be due O \u2019Brien under the contract in the final certificate issued by him to O \u2019Brien. Furthermore, Dickinson cannot be regarded as a third party in his dealings with O\u2019Brien. He was the agent of\u25a0 appellant and all payments made and orders given by him were as such agent for appellant. Whatever O\u2019Brien took or received from Dickinson on account of moneys due tinder his contract with appellant must, on the evidential facts undisputed on this record, be treated as the property of and coming from appellant, and therefore such acceptance by O\u2019Brien cannot be regarded or treated as a waiver by him of his right to a lien. Kendall v. Fader, 199 Ill. 294, is decisive on this point.\nBeference has been made to the fact that Bolf, while secretary of appellant, acted as the legal adviser of O\u2019Brien in the initiatory steps leading to the filing of the intervening petition and that he advised him to preserve his rights to a lien, and that O \u2019Brien acted under such advice in the steps which he subsequently took in an attempt to conserve and protect his rights in the premises. No bad faith is imputed to Bolf in what he did for O\u2019Brien. He was cognizant of the legal status of appellant and O\u2019Brien under the contract. As secretary of appellant he kept the accounts and from his books and memoranda was able to make up a correct account impartially between the parties and one that all concerned might in the exercise of good, judgment be treated as trustworthy and reliable. Both appellant and' appellees have, by calling Rolf as their witness, impliedly certified to his credibility and reliability, and we find nothing in his testimony or actions warranting our disregarding such implied representation.\nThere is no merit in appellant\u2019s resistance of O\u2019Brien\u2019s claim. O\u2019Brien, as the record shows, lived up to his contract as best he could, struggling and striving continually against the failure by appellant to make payments due him under the contract as the work progressed. This failure constantly embarrassed O\u2019Brien, put him in financial straits with his creditors and finally compelled him to assign his rights under the contract to Sedgwick for the benefit of those having claims against him arising out of the construction of appellant\u2019s building, all of which was occasioned by the improvident managers of appellant company launching upon an extended building enterprise without1- any cash capital or resources.\nMost of the defenses interposed are of an extremely technical legal character and are unavailing to defeat appellees\u2019 claim as against the strong evidential facts appearing in the record of O\u2019Brien\u2019s having satisfactorily performed his part of the contract in accordance with its terms and complied with all the formal requirements of the statute necessary to preserve his right to a mechanic\u2019s lien.\nAfter a painstaking consideration of all the questions raised in the record and briefs in this case, we are unable to discover any error justifying a reversal of the decree of the Superior Court, and the decree will therefore be affirmed.\nAffirmed.", "type": "majority", "author": "Mr. Justice Holdom" } ], "attorneys": [ "Helmeb, Moulton & Whitman, for appellant.", "Mabston & Tuttle, for appellees." ], "corrections": "", "head_matter": "Concord Apartment House Co. v. W. D. O\u2019Brien et al.\nGen. No. 12,605.\n1. Mechanic\u2019s lien\u2014tohen contract sufficient to support decree for. Where the contract in question fixes with certainty the time for final completion of the work and payment of the money within the periods fixed hy the statute, it is sufficient to support a lien.\n2. Mechanic\u2019s lien\u2014when contract does not waive right to. A provision in the contract of the general contractor by which he agrees to furnish, when requested, releases of claims for lien by third parties, does not affect the right of such general contractor to enforce a lien in his own behalf.\n3. Mechanic\u2019s lien\u2014character of undertaking essential to waive. In order to waive by contract the right to a mechanic\u2019s lien, there must be an express covenant or a covenant resulting by implication from the language used so plain that a mechanic can so understand without seeking a professional interpretation as to its legal effect.\n4. Mechanic\u2019s lien\u2014when acceptance of security does not waive right to. The acceptance by a contractor of security for payments maturing from time to time, does not affect his right to enforce his lien with respect to the balance subsequently accruing with respect to which he has accepted no security.\n5. Abchitect\u2019s certificate\u2014how far binding. Where after the work has been completed an accounting has been taken and an architect\u2019s certificate issued stating the balance due, the same, as to such balance, is binding upon the parties in the absence of fraud, accident or mistake, where the contract between the parties made the architect the arbiter of disputes between the parties.\n. Intervening petition. Appeal from the Superior Court of Cook county; the Hon. Theodobe Bbentaito, Judge, presiding. Heard in this court at the October term, 1905.\nAffirmed.\nOpinion filed October 8, 1906.\nStatement by the Court. This proceeding is in the nature of an intervening .petition grounded upon the answer as amended of appellees to the original petition for a mechanic\u2019s lien upon the land and building of appellant, filed June 11,1896, by the Western Planing & Manufacturing Company, to which amended petition a demurrer was interposed by appellant and sustained by the Superior Court and the amended petition dismissed. An appeal from the order was prosecuted to this court by appellees and the action of the Superior Court in so sustaining the demurrer and dismissing the amended petition, this court on that appeal adjudged to be error, and the cause was remanded to the Superior Court for further proceedings. Sedgwick v. Concord Apartment House Co., 104 Ill. App. 5. In this case there will be found a full and succinct statement of the averments of the amended petition to which we refer and adopt as the statement here, not deeming it necessary or expedient to again set it forth.\nUpon a redocketing of the cause pursuant to the mandate of this court, appellant filed its answer September 5, 1903, which it subsequently amended February 20, 1905. In the answer as amended, appellant admits the contract with O\u2019Brien of May'28, 1895, for $8,500, under which appellees base their claim for a lien, but deny that O \u2019Brien did any work under it, and aver that the contract expired by limitation September 15, 1895, and that thereafter on \"December 21, 1895, a-verbal agreement was made with O\u2019Brien to do the work specified in the former written contract for $10,050, but that neither the time of completing the work nor for final payment was fixed by the verbal agreement, and that the verbal agreement was not in any sense an extension of the first contract or any of its provisions, or that the increase of $1,500 in the price was compensation for loss O\u2019Brien may have suffered by reason of his not having, to that time, entered upon the performance of the original contract. Denies 0 \u2019Brien did any extra work or furnished extra material or that the work undertaken to be done by the verbal contract was fully performed to the satisfaction of Wheatley as superintendent, or that Wheatley issued a final certificate under the terms of the contract, or that anything is due 0 \u2019Brien or Sedgwick, his assignee thereunder. Denies work was completed under verbal contract prior to September, 1896, and avers O\u2019Brien never fully performed the work contemplated by the verbal contract. In arguendo states that if all conditions of contract of May 28, 1895, were part of subsequent verbal agreement, that then appellees had no right to a lien for work done, because under second paragraph article 8 of that contract, O\u2019Brien stipulated to release any lien he might have upon request, and in the answer appellant demands that appellees forthwith execute and furnish appellant with an absolute release of all claims and liens and dismiss their intervening petition.\nAppellant further claims that appellees are not entitled to any lien, because it avers that O\u2019Brien received collateral security for a large portion of the contract price of the work done, by acceptances of W. P. Dickinson & Co. in favor of American Radiator Co. and the Holland Radiator Co. for materials, guaranty by Dickinson & Co. of an account with Crane Co. for materials, acceptance given the Illinois Malleable Iron Co. for materials, also that a number of orders given by O\u2019Brien & Co. on Dickinson & Co., accepted by them, and garnishments on judgments against O\u2019Brien paid by appellant and by Dickinson & Co.\nUpon the issues thus joined the cause was referred to Master in Chanc\u00e9ry Healy, who reported -in favor of appellees\u2019 claim, and after overruling the exceptions of appellant to the master\u2019s report, a decree was entered establishing a mechanic\u2019s lien upon the property of appellant set out in the intervening petition for the sum of $4,105 and costs of suit, to reverse which decree this appeal is prosecuted.\nHelmeb, Moulton & Whitman, for appellant.\nMabston & Tuttle, for appellees." }, "file_name": "0437-01", "first_page_order": 455, "last_page_order": 464 }