{
  "id": 8499260,
  "name": "Rosweld W. Weld, Appellee, v. First National Bank of Englewood, Appellant",
  "name_abbreviation": "Weld v. First National Bank",
  "decision_date": "1911-11-14",
  "docket_number": "Gen. No. 15,832",
  "first_page": "8",
  "last_page": "12",
  "citations": [
    {
      "type": "official",
      "cite": "166 Ill. App. 8"
    }
  ],
  "court": {
    "name_abbreviation": "Ill. App. Ct.",
    "id": 8837,
    "name": "Illinois Appellate Court"
  },
  "jurisdiction": {
    "id": 29,
    "name_long": "Illinois",
    "name": "Ill."
  },
  "cites_to": [],
  "analysis": {
    "cardinality": 432,
    "char_count": 8498,
    "ocr_confidence": 0.505,
    "sha256": "ded2d46abb998391b46509fb8e802ec99d0fda02f184794400a6cc93c092766f",
    "simhash": "1:2b94b7e319268dda",
    "word_count": 1396
  },
  "last_updated": "2023-07-14T20:05:11.617746+00:00",
  "provenance": {
    "date_added": "2019-08-29",
    "source": "Harvard",
    "batch": "2018"
  },
  "casebody": {
    "judges": [],
    "parties": [
      "Rosweld W. Weld, Appellee, v. First National Bank of Englewood, Appellant."
    ],
    "opinions": [
      {
        "text": "Mr. Presiding Justice Baldwin\ndelivered the opinion of the court.\nOil September 29, 1906, the parties entered into a written contract for the stone work upon a new building to be constructed for appellant. The contract provided that the work should be done under the direction of the architect, upon whose certificates payments were to be made to the contractor, the final certificate- of the architect to be conclusive evidence of the performance of the contract, the work to be completed on or before December 1, 1906, and if not thus completed the contractor to pay to the owner $25 per day, as liquidated damages, for every day thereafter until the completion of the work.\nThe contractor did not complete the work at the time specified, but wlien it was completed be made_application to the architect for his final certificate, which was furnished in the following form, showing both printed and written parts (the written parts, except the check marks made in the space after the sign \u2018 \u2018 $ \u201d, which are made in ink, \u2014 appearing in italics):\nCertificate No. 65.\n\u2018 \u2018Building No. 176. $1,211 50(100 September 3, 1907.\nTo First National Bank of Englewood:\nThis is to Certify, That B. W. Weld & Co., Contractor for the... .Granite work... ..of your building at Nos. 443-445 W. 63rd St., Chicago, Ill\u2019s,... .is entitled to a final payment of One thousand two hundred eleven and 50\\100 Dollars, by the terms of contract.\nJulian Barnes,\nArchitect.\nEemarks: This contractor was forty-eight (48) days beyond the time specified for finishing the work under his contract, for which the contract provides a penalty of $25.00 per day. Statements showmg that the building is free from claims to accompany this certificate.\nJ. B.\u201d\nContract Price,.$5,500.00\nExtra Work, .$\nDeduction .$\nTotal, ...$5,500.00\nFormer Certificates, .$4,288.50\nPresent Certificate, .$1,211.50\nTotal, .$5,500.00\nBalance, ...$\nAppellee brought an action of the first class in the Municipal Court of Chicago; the declaration contained several special counts, and the common counts, together with a bill of particulars, setting out the claim of the plaintiff, which included extra work, labor and material, etc., the whole aggregating $1,561.85.\nA jury being waived the cause was tried by the court, and at the trial the bank tendered to Weld the sum of $11.50, which, it claimed, was all that was due. The tender was declined, and the cause proceeded.\nAppellee offered in evidence the written contract together with the architect\u2019s final certificate, and also introduced\u2019 testimony as to the amount of accrued interest, whereupon he rested his case.\nAppellant did not offer any evidence, nor produce any witnesses. At the close of appellee\u2019s case, however, counsel for appellant made the following statement : \u201cDefendant offers to prove that the architect decided that there was a deduction from the balance remaining unpaid on the contract price, for forty-eight days\u2019 delay, at $25 per day.\u201d To this offer the court sustained an objection, and, no further testimony being offered, found the issues in favor of appellee, \u2014 assessed its damages at $1,322.52, \u2014 being $1,211.50 mentioned in the certificate, with interest thereon.\nThereupon, and on the same day, appellant moved for a new trial, which was denied. He then entered a motion in arrest of judgment, which was also overruled, and judgment was entered upon the finding, whereupon an appeal was prayed and allowed. The cause was thus tried and disposed of June 29, 1909.\nSubsequently, and on the 10th of July, 1909, appellant moved to vacate the judgment theretofore entered, basing his motion upon the grounds that if the architect\u2019s certificate does show a balance of only $11.50, there was a mistake and did not represent the decision and judgment of the architect; that a new certificate has been issued by the architect for the exact sum of $11.50. In support of this motion appellant filed the affidavit of Julian Barnes, the architect, who swore that he decided there should be a deduction from the balance remaining unpaid of $25 per day for forty-\u00e9ight days; that his decision was that there was due plaintiff but $11.50, and that he had made a new certificate for that sum, and tendered it to plaintiff. After a hearing, this motion to vacate the judgment was overruled.\nAppellant files nineteen assignments of error, but his brief and arguments are directed to show, first, that a proper interpretation of the original architect\u2019s certificate showed a balance due of only $11.50; second, that if not thus interpreted, then there was an evident error in drafting the certificate, and evidence was admissible to correct the error; third, if the question of damages was, by contract, submitted to the architect, and he failed to pass upon it, then the certificate was not binding in that particular, and evidence was admissible to show the damages, and fourth, if the question of damages for delay was not submitted to the architect by the contract, then the court should have admitted evidence and made a finding with respect thereto.\nIt is manifest that the architect could not, by his certificate, determine any question not submitted to him by file provisions of the contract between the parties. A careful examination of the contract shows that, while it provides that the final certificate of the architect should be conclusive evidence of the completion of the work, it does not contain any provision for his certifying as to any delay in its completion. Consequently his finding or certifying in respect thereto, would in no manner bind the parties.\nThe offer made by appellant at the close of plaintiff\u2019s case, \u201cto prove that the architect decided that there was a deduction from the balance remaining unpaid on the contract price, for forty-eight days\u2019 delay at $25 per day,\u201d was properly refused. Even if the physical presence of the witnesses had been waived, the court properly refused the offer, because, first, to prove' what the 'architect had \u2018 \u2018 decided \u2019 \u2019 would be merely to prove a conclusion; and, second, the contract nowhere conferred any authority upon the architect to decide this particular question.\nAs to the proceeding had in the case subsequent to the entry of judgment on the 29th of June, 1909, wliich had been preceded by a trial and a motion in arrest of judgment, \u2014 as a matter of practice, we do not think the affidavit of the architect offered and heard in support of a motion to vacate the judgment, could avail appellant, even if the affidavit had presented a meritorious defense; but, in the view we have expressed that the architect had no authority under the contract to certify as to this matter, it follows that the affidavit did not present any sufficient grounds for a new trial, even if it had been filed and heard in support of a motion for a new trial instead of a motion in arrest of judgment.\nBy introducing the contract, and the certificate of the architect, which was made \u201cconclusive evidence of the completion of the work,\u201d the plaintiff made a prima facie case, and if the defendant wished to establish an offset or counterclaim for failure on the part of the contractor to complete the work within the time specified, he should have offered testimony- showing the number of days\u2019 delay, if any. The contract between the parties has determined the measure of'damages for the delay at $25 per day; however, the certificate of the architect was not evidence of the fact that there had been any given number of days\u2019 delay, because he had not been given, by the contract, any authority to certify in relation to that question.\nFinding no reversible error, judgment of the court below will be affirmed.\nJudgment affirmed.",
        "type": "majority",
        "author": "Mr. Presiding Justice Baldwin"
      }
    ],
    "attorneys": [
      "William A. Doyle, for appellant; Joseph J. Thompson, of counsel.",
      "Weissenbach, Shrimski & Meloan, for appellee."
    ],
    "corrections": "",
    "head_matter": "Rosweld W. Weld, Appellee, v. First National Bank of Englewood, Appellant.\nGen. No. 15,832.\n1. Contracts \u2014 effect of architect\u2019s certificate. An architect's certificate does not bind the parties to a bnilding contract with respect to any matter not left to the determination of the architect.\n2. Evidence \u2014 when offer of \u201cproof insufficient. An offer of proof is insufficient if instead of specifying facts it merely embodies statements of conclusions.\nAppeal from the Municipal Court of Chicago; the Hon. Hosea W. Wells, Judge, presiding. Heard in the Branch Appellate Court at the October term, 1909.\nAffirmed.\nOpinion filed November 14, 1911.\nRehearing denied November 28, 1911.\nWilliam A. Doyle, for appellant; Joseph J. Thompson, of counsel.\nWeissenbach, Shrimski & Meloan, for appellee."
  },
  "file_name": "0008-01",
  "first_page_order": 38,
  "last_page_order": 42
}