{ "id": 8520595, "name": "BOLTON CORP. v. T. A. LOVING COMPANY", "name_abbreviation": "Bolton Corp. v. T. A. Loving Co.", "decision_date": "1985-10-01", "docket_number": "No. 8410SC1215", "first_page": "90", "last_page": "97", "citations": [ { "type": "official", "cite": "77 N.C. App. 90" } ], "court": { "name_abbreviation": "N.C. Ct. App.", "id": 14983, "name": "North Carolina Court of Appeals" }, "jurisdiction": { "id": 5, "name_long": "North Carolina", "name": "N.C." }, "cites_to": [ { "cite": "197 S.E. 2d 874", "category": "reporters:state_regional", "reporter": "S.E.2d", "year": 1973, "opinion_index": 0 }, { "cite": "283 N.C. 665", "category": "reporters:state", "reporter": "N.C.", "case_ids": [ 8559748, 8559781, 8559761, 8559797, 8559770 ], "year": 1973, "opinion_index": 0, "case_paths": [ "/nc/283/0665-01", "/nc/283/0665-04", "/nc/283/0665-02", "/nc/283/0665-05", "/nc/283/0665-03" ] }, { "cite": "196 S.E. 2d 585", "category": "reporters:state_regional", "reporter": "S.E.2d", "weight": 2, "year": 1973, "pin_cites": [ { "page": "587" } ], "opinion_index": 0 }, { "cite": "18 N.C. App. 282", "category": "reporters:state", "reporter": "N.C. App.", "case_ids": [ 8548805 ], "weight": 2, "year": 1973, "pin_cites": [ { "page": "284" } ], "opinion_index": 0, "case_paths": [ "/nc-app/18/0282-01" ] }, { "cite": "68 S.E. 2d 805", "category": "reporters:state_regional", "reporter": "S.E.2d", "weight": 2, "opinion_index": 0 }, { "cite": "235 N.C. 119", "category": "reporters:state", "reporter": "N.C.", "case_ids": [ 8621522 ], "opinion_index": 0, "case_paths": [ "/nc/235/0119-01" ] }, { "cite": "89 S.E. 2d 860", "category": "reporters:state_regional", "reporter": "S.E.2d", "opinion_index": 0 }, { "cite": "243 N.C. 92", "category": "reporters:state", "reporter": "N.C.", "case_ids": [ 8621383 ], "opinion_index": 0, "case_paths": [ "/nc/243/0092-01" ] }, { "cite": "106 S.E. 2d 229", "category": "reporters:state_regional", "reporter": "S.E.2d", "opinion_index": 0 }, { "cite": "249 N.C. 279", "category": "reporters:state", "reporter": "N.C.", "case_ids": [ 8613718 ], "opinion_index": 0, "case_paths": [ "/nc/249/0279-01" ] }, { "cite": "132 S.E. 2d 886", "category": "reporters:state_regional", "reporter": "S.E.2d", "weight": 3, "pin_cites": [ { "page": "890" } ], "opinion_index": 0 }, { "cite": "260 N.C. 382", "category": "reporters:state", "reporter": "N.C.", "case_ids": [ 8574870 ], "weight": 3, "pin_cites": [ { "page": "388" } ], "opinion_index": 0, "case_paths": [ "/nc/260/0382-01" ] }, { "cite": "171 S.E. 2d 56", "category": "reporters:state_regional", "reporter": "S.E.2d", "year": 1969, "opinion_index": 0 }, { "cite": "7 N.C. App. 36", "category": "reporters:state", "reporter": "N.C. App.", "case_ids": [ 8547626 ], "year": 1969, "opinion_index": 0, "case_paths": [ "/nc-app/7/0036-01" ] }, { "cite": "225 S.E. 2d 829", "category": "reporters:state_regional", "reporter": "S.E.2d", "year": 1976, "opinion_index": 0 }, { "cite": "290 N.C. 308", "category": "reporters:state", "reporter": "N.C.", "case_ids": [ 8561061, 8561029, 8561098, 8561046, 8561079 ], "year": 1976, "opinion_index": 0, "case_paths": [ "/nc/290/0308-03", "/nc/290/0308-01", "/nc/290/0308-05", "/nc/290/0308-02", "/nc/290/0308-04" ] }, { "cite": "224 S.E. 2d 293", "category": "reporters:state_regional", "reporter": "S.E.2d", "year": 1976, "opinion_index": 0 }, { "cite": "29 N.C. App. 415", "category": "reporters:state", "reporter": "N.C. App.", "case_ids": [ 8556168 ], "year": 1976, "opinion_index": 0, "case_paths": [ "/nc-app/29/0415-01" ] }, { "cite": "136 S.E. 2d 665", "category": "reporters:state_regional", "reporter": "S.E.2d", "weight": 3, "year": 1964, "pin_cites": [ { "page": "667" }, { "page": "668" } ], "opinion_index": 0 }, { "cite": "262 N.C. 284", "category": "reporters:state", "reporter": "N.C.", "case_ids": [ 8567105 ], "weight": 3, "year": 1964, "pin_cites": [ { "page": "286" }, { "page": "287" } ], "opinion_index": 0, "case_paths": [ "/nc/262/0284-01" ] }, { "cite": "146 S.E. 2d 390", "category": "reporters:state_regional", "reporter": "S.E.2d", "year": 1966, "pin_cites": [ { "page": "393" } ], "opinion_index": 0 }, { "cite": "266 N.C. 489", "category": "reporters:state", "reporter": "N.C.", "case_ids": [ 8561250 ], "year": 1966, "pin_cites": [ { "page": "493" } ], "opinion_index": 0, "case_paths": [ "/nc/266/0489-01" ] }, { "cite": "110 S.E. 2d 316", "category": "reporters:state_regional", "reporter": "S.E.2d", "year": 1959, "pin_cites": [ { "page": "317" } ], "opinion_index": 0 }, { "cite": "250 N.C. 713", "category": "reporters:state", "reporter": "N.C.", "case_ids": [ 8625972 ], "year": 1959, "pin_cites": [ { "page": "714" } ], "opinion_index": 0, "case_paths": [ "/nc/250/0713-01" ] } ], "analysis": { "cardinality": 712, "char_count": 14529, "ocr_confidence": 0.763, "pagerank": { "raw": 2.2050037991065377e-07, "percentile": 0.7756066087250647 }, "sha256": "33c5df017bd1c9dbe94554c15b0c034b35148fc5393b4d9ceb6fb98ac1671a22", "simhash": "1:1363e0f90ccb4290", "word_count": 2341 }, "last_updated": "2023-07-14T21:22:01.691260+00:00", "provenance": { "date_added": "2019-08-29", "source": "Harvard", "batch": "2018" }, "casebody": { "judges": [ "Chief Judge Hedrick and Judge Arnold concur." ], "parties": [ "BOLTON CORP. v. T. A. LOVING COMPANY" ], "opinions": [ { "text": "COZORT, Judge.\nPlaintiffs principal assignment of error concerns the trial court\u2019s granting summary judgment for defendant. At the center of the controversy is a document entitled \u201cRelease in Full\u201d which signifies a settlement agreement between defendant and plaintiffs insurance company. Plaintiff contends the trial court erred in granting summary judgment because it never ratified the document, or that at most, only ratified part of the agreement, and nevertheless by the terms of the document retained its right to sue. For the reasons stated below, we affirm.\nPlaintiff and defendant were prime contractors in the construction of the Walter R. Davis Library at the University of North Carolina at Chapel Hill.\nIn September 1979, the State entered into contracts with plaintiff and defendant for the construction of the library. Defendant was the general contractor for the project and was responsible for furnishing labor and materials and performing certain work on this project. In addition to furnishing labor and materials, defendant was designated \u201cProject Expediter,\u201d and as such, was responsible for coordinating all schedules and ongoing projects in the course of construction. Plaintiff was responsible for installation of the library\u2019s heating, ventilation, and air conditioning system.\nBoth plaintiffs and defendant\u2019s contract with the State contained identical provisions specifying that work would be performed within 930 consecutive calendar days. The construction project, however, experienced numerous delays and was not completed until well after the 930-day time period.\nOn 14 April 1983, a water line at the unfinished library was ruptured by plaintiff\u2019s construction crew. In the following months, defendant filed claims with plaintiff\u2019s insurance carrier, Aetna Casualty and Surety Co., for delays and damages to property.\nOn 16 November 1983, plaintiff filed its lawsuit against the defendant seeking damages it allegedly suffered by reason of defendant\u2019s delay in completing its work on the library and the resulting interference with plaintiffs work on the library. In its complaint plaintiff alleged that defendant was responsible for maintaining certain progress on its own work and scheduling and coordinating the work of the other prime contractors; that defendant failed to timely complete its work as required by the September 1979 contract; and that plaintiff was delayed in performing its contract with the State and suffered $350,000 in damages, by reason of defendant\u2019s failure to maintain progress and failure to coordinate progress on the job. Plaintiff contended that defendant was liable to it both by reason of breach of contract and under a theory of negligence.\nOn 23 January 1984, defendant filed its answer denying the bulk of plaintiff\u2019s allegations, moved to dismiss plaintiff\u2019s complaint under Rule 12(b)(6), and counterclaimed alleging that it had been damaged by reason of the broken water line for which plaintiff was responsible and also that plaintiff was liable to defendant for failure to pay its pro rata share of the power bills.\nOn 21 February 1984, upon receipt of $136,445.29 from plaintiff\u2019s insurer in the ruptured water pipe claim it had filed with the insurer, defendant executed a \u201cRelease in Full\u201d in which defendant\nreleasefd] and forever discharge[d] the said Bolton Corporation and their representatives, Aetna Casualty & Surety Co. and all other persons, firms or corporations from all claims, demands, damages, actions, or causes of action, on account of damage to property, The Central Library, Chapel Hill, N. C. which occurred on or about the 14th day of April, 1983, by reason of water pipe breaking and of and for all claims or demands whatsoever in law or in equity, which it and its successors can, shall or may have by reason of any matter, cause or thing whatsoever prior to the date hereof.\n* * * *\nIt is Understood and Agreed that this is a full and final release of all claims of every nature and kind whatsoever, and releases claims that are known and unknown, suspected and unsuspected.\nOnly defendant and accompanying witnesses signed the document.\nThe next day, 22 February 1984, plaintiff filed its reply to defendant\u2019s counterclaim asserting in its concluding paragraph that \u201cany recovery sought is barred by the doctrine of accord and satisfaction, settlement and release.\u201d\nOn 3 August 1984, defendant moved for summary judgment pursuant to Rule 56, N.C. Rules Civ. Proc. Both parties submitted briefs, memoranda, and supporting exhibits. Defendant contended that plaintiffs plea of settlement and release was a binding ratification of the settlement between plaintiffs insurer, Aetna Casualty, and defendant, which barred plaintiffs original claim. The trial court granted defendant\u2019s motion for summary judgment in an order filed 13 September 1984.\nOn the issue of ratification of settlement, our Supreme Court has stated:\nIt seems to be well-nigh the universal holding in this country that where an insurance carrier makes a settlement in good faith, such settlement is binding on the insured as between him and the insurer, but that such settlement is not binding as between the insured and a third party where the settlement was made without the knowledge or consent of the insured or over his protest, unless the insured in the meantime has ratified such settlement.\nLampley v. Bell, 250 N.C. 713, 714, 110 S.E. 2d 316, 317 (1959). In Patterson v. Lynch, 266 N.C. 489, 493, 146 S.E. 2d 390, 393 (1966), the Supreme Court noted that \u201c \u2018[o]ne of the most unequivocal methods of showing a ratification of an agent\u2019s unauthorized act is by bringing an action or basing a defense on the unauthorized act with full knowledge of the material facts.\u2019 [Citation omitted.]\u201d\nHere it is undisputed that at the time plaintiffs insurer settled with the defendant, plaintiff had not consented to the settlement but that at the time plaintiff filed its reply to defendant\u2019s counterclaim plaintiff had full knowledge of the material facts of the settlement and \u201cRelease in Full.\u201d Therefore, the question we must decide is whether plaintiff has ratified the compromise settlement by pleading the settlement and release in its reply as a bar to defendant\u2019s counterclaim, and, if so, whether the ratification of the settlement bars plaintiffs claim for damages presented in this lawsuit. At least in the context of motor vehicle negligence cases, this question has repeatedly been answered in the affirmative. See, e.g., Keith v. Glenn, 262 N.C. 284, 136 S.E. 2d 665 (1964); Johnson v. Austin, 29 N.C. App. 415, 224 S.E. 2d 293, cert. denied, 290 N.C. 308, 225 S.E. 2d 829 (1976); White v. Perry, 7 N.C. App. 36, 171 S.E. 2d 56 (1969).\nIn Keith v. Glenn, supra, the court phrased the issue as follows: \u201cMay plaintiff maintain his action against defendant and at the same time rely on the release given by defendant to defeat the counterclaim?\u201d It ruled that \u201c[u]nless we are to depart from logic and overrule prior decisions of this Court, the answer must be \u2018No.\u2019 \u201d 262 N.C. at 286, 136 S.E. 2d at 667.\nA consummated agreement to compromise and settle disputed claims is conclusive and binding on the parties to the agreement and those who knowingly accept its benefits. Bradford v. Kelly, 260 N.C. 382, 132 S.E. 2d 886; Cannon v. Parker, 249 N.C. 279, 106 S.E. 2d 229; Houghton v. Harris, 243 N.C. 92, 89 S.E. 2d 860; Snyder v. Oil Co., 235 N.C. 119, 68 S.E. 2d 805 ....\nId.\nWhen a plaintiff pleads settlement and release as a bar to defendant\u2019s counterclaim, the pleading constitutes a ratification of the settlement and bars both plaintiffs and defendant\u2019s actions. Keith v. Glenn, supra; Johnson v. Austin, supra; White v. Perry, supra. We find this case to be governed by this rule.\nPlaintiff argues that since defendant\u2019s original claim with Aetna was for the water damage incident, the resulting release should be narrowly construed in such a way as to limit ratification to the amount paid therefor. Such an interpretation is contrary to existing law and the broad language of the release itself. The release was not only for the water damage claim but \u201cof and for all claims or demands whatsoever in law or in equity, which [TALCO] can, shall or may have\u201d prior to the signing date of the release. A principal may not ratify the act of his agent in part and repudiate such act in part: \u201c \u2018[H]e cannot take the rose without the thorns.\u2019 [Citations omitted.]\u201d Keith v. Glenn, supra, 262 N.C. at 287, 136 S.E. 2d at 668.\nIn the case sub judice, plaintiff had several options open to it, each of which has its benefits and risks or burdens. The first option the plaintiff had was to ratify the settlement. At least two ways a plaintiff may ratify a settlement are by (1) pleading settlement and release to bar defendant\u2019s counterclaim, or (2) by moving to strike the counterclaim based on the release. McKinney v. Morrow, 18 N.C. App. 282, 196 S.E. 2d 585, cert. denied, 283 N.C. 665, 197 S.E. 2d 874 (1973). The benefit of such action is to bar defendant\u2019s counterclaim and thus avoid the possibility of having to pay a judgment without the benefit of liability insurance. The burden of such action is that plaintiffs claims are also barred.\nAs second option, plaintiff can choose not to ratify the compromise settlement. The benefit of such action is plaintiff preserves its right of action against the defendant. See Bradford v. Kelly, 260 N.C. 382, 132 S.E. 2d 886 (1963); McKinney v. Morrow, supra. The burden of such an action is that defendant still has the right to bring its counterclaim; and while plaintiff may maintain its action, it does so at the risk that if defendant prevails, plaintiff may have to pay a judgment without the benefit of liability insurance. Bradford v. Kelly, supra; McKinney v. Morrow, supra. Likewise, if defendant prevails, it can look only to the plaintiff for payment because, by settling with the insurer, defendant has bought his peace with the insurer and released it from liability. See Bradford v. Kelly, supra, 260 N.C. at 388, 132 S.E. 2d at 890.\nOf course, as a matter of equity, \u201c[i]f the defendant does obtain a judgment against the plaintiff, the amount of liability must be diminished by the amount previously paid to the defendant by plaintiffs insurance carrier.\u201d McKinney v. Morrow, supra, 18 N.C. App. at 284, 196 S.E. 2d at 587, citing Bradford v. Kelly, supra.\nFinally, plaintiff relies heavily on the final paragraph of the \u201cRelease in Full\u201d which states:\nIt is further understood and agreed that any party hereby released admits no liability to the undersigned or any others, shall not be estopped or otherwise barred from asserting, and expressly reserves the right to assert any claim or cause of action such party may have against the undersigned or any others.\nPlaintiff argues that even if it did ratify the settlement and release that the above language gives it the right to maintain its action. Had the plaintiff been a true party to the settlement, that is, if plaintiff had consented to the settlement at the time the \u201cRelease in Full\u201d was executed, plaintiffs argument would have validity. Plaintiff, however, did not consent to the settlement at the time the \u201cRelease in Full\u201d was executed. As such the above language is merely a restatement of the law concerning a non-consenting insured\u2019s rights: that by not consenting to its insurer\u2019s settlement and release, it retained its right to pursue any claims it may have against the defendant. However, once plaintiff ratified the compromise settlement, it gave up this right.\nTo allow plaintiff to plead the release to bar defendant\u2019s counterclaims and yet allow plaintiff to pursue his original claims would materially change the terms or understanding upon which defendant bargained with plaintiffs insurer. When a defendant-claimant settles with plaintiff\u2019s insurer without plaintiffs knowledge or consent, defendant does so with the knowledge that the plaintiff may still pursue whatever claims it may have against the defendant. Defendant, however, may still take comfort in the fact that unless and until plaintiff-insured ratifies the settlement, defendant may seek full recovery for his claims against the plaintiff, though it may no longer look to plaintiffs insurer for the payment of any judgment it may obtain.\nTo adopt plaintiffs position in this case would in effect prevent insurers from settling claims, in good faith, without the insured\u2019s consent. A defendant-claimant would have little incentive to compromise its claims if a plaintiff-insured, without ratifying the settlement and compromising its claims, could pursue its claims in full and at the same time bar the defendant's claims and thereby prevent the defendant from pursuing a full recovery.\nIn sum, by pleading settlement and release in bar to defendant\u2019s counterclaim, plaintiff ratified the compromise settlement and effectively barred defendant\u2019s counterclaim, but at the same time, plaintiff compromised its claims and barred its original action as well. We hold that the trial court properly granted summary judgment for the defendant.\nSince summary judgment was properly granted, it is unnecessary to address the parties\u2019 remaining assignments of error.\nAffirmed.\nChief Judge Hedrick and Judge Arnold concur.", "type": "majority", "author": "COZORT, Judge." } ], "attorneys": [ "Akins, Mann, Pike & Mercer by J. Jerome Hartzell for plaintiff appellant.", "Poyner, Geraghty, Hartsfield & Townsend by David W. Long, Cecil W. Harrison and Susanna K. Gilchrist; and Taylor, Warren, Kerr & Walker by John H. Kerr for defendant appellee." ], "corrections": "", "head_matter": "BOLTON CORP. v. T. A. LOVING COMPANY\nNo. 8410SC1215\n(Filed 1 October 1985)\nPrincipal and Agent \u00a7 6; Compromise and Settlement \u00a7 1.1\u2014 compromise between defendant and plaintiffs insurer \u2014 pleaded as bar to defendant\u2019s counterclaim \u2014 ratified by plaintiff\nThe trial court correctly granted summary judgment for defendant in an action arising from a construction dispute where plaintiff filed an action against defendant, defendant filed an answer and counterclaim against plaintiff, plaintiffs insurer settled with defendant without plaintiffs consent, and plaintiff asserted that defendant\u2019s counterclaim was barred by the settlement. When a plaintiff pleads settlement and release as a bar to defendant\u2019s counterclaim, the pleading constitutes a ratification of the settlement and bars both plaintiffs and defendant\u2019s actions.\nAPPEAL by plaintiff from Brannon, Judge. Order entered 13 September 1984 in Superior Court, WAKE County. Heard in the Court of Appeals 19 August 1985.\nAkins, Mann, Pike & Mercer by J. Jerome Hartzell for plaintiff appellant.\nPoyner, Geraghty, Hartsfield & Townsend by David W. Long, Cecil W. Harrison and Susanna K. Gilchrist; and Taylor, Warren, Kerr & Walker by John H. Kerr for defendant appellee." }, "file_name": "0090-01", "first_page_order": 122, "last_page_order": 129 }